Loading...
Item 10D General ConditionsAIA Document A2011CMaT" -1992 General Conditions of the Contract for Construction where the Construction Manager is NOT a Constructor for the following PROJECT: (Name and location or address): City of Southlake Department of Public Safety Facility Southlake, Texas Approximately 12 acres at the northeast corner of East Dove Road and North White Chapel Road. THE OWNER: (Name and address): Mr. Andy Wambseanss, Mao City of Southlake 667 N. Carroll Avenue Southlake, Texas 76092 THE ARCHITECT: (Name and address): RPGA Design Group, Inc., General Corporation 101 S. Jennings Avenue Suite 100 Fort Worth, Texas 76104 TABLE OF ARTICLES 1 GENERAL PROVISIONS 2 OWNER 3 CONTRACTOR 4 ADMINISTRATION OF THE CONTRACT 5 SUBCONTRACTORS 6 CONSTRUCTION BY OWNER OR BY OTHER CONTRACTORS 7 CHANGES IN THE WORK 8 TIME 9 PAYMENTS AND COMPLETION 10 PROTECTION OF PERSONS AND PROPERTY 11 INSURANCE AND BONDS 12 UNCOVERING AND CORRECTION OF WORK 13 MISCELLANEOUS PROVISIONS This document has important legal consequences. Consultation with an attorney is encouraged with respect to its completion or modification. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA" Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 1 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) 14 TERMINATION OR SUSPENSION OF THE CONTRACT AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA" Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) INDEX Acceptance of Nonconforming Work Acceptance of Work Access to Work Accident Prevention Acts and Omissions Addenda Additional Costs, Claims for Additional Inspections and Testing Additional Time, Claims for ADMINISTRATION OF THE CONTRACT Advertisement or Invitation to Bid Aesthetic Effect Allowances All -risk Insurance Applications for Payment Approvals Arbitration Architect Architect, and Certificate 9.6.6, 9.9.3. 12.3 9.6.6, 9.8.2, 9.9.3, 9.10.1, 9.10.3 3.16, 6.2.1, 12.1 4.6.6, 10 3.2.1, 3.2.2, 3.3.2, 3.12.8, 3.18, 4.6.6, 4.6.2., 4.7.9, 8.3.1, 10.1.4, 10.2.5, 13.4.2, 13.7, 14.1 1.1.1, 3.11 4.7.6, 4.7.7, 4.7.9, 6.1.1, 10.3 4.6.10, 9.8.2, 12.2.1, 13.5 4.7.6, 4.7.8, 4.7.9, 8.3.2, 10.3 3.3.3, 4, 9.4, 9.5 1.1.1 4.6.20, 4.9.1 3.8 11.3.1.1 4.6.9, 7.3.7, 9.2, 9.3, 9.4, 9.5.1, 9.6.3, 9.8.3, 9.10.1, 9.10.3, 9.10.4, 11.1.3, 14.2.4 2.4, 3.3.3, 3.5, 3.10.3, 3.12.4 through 3.12.8, 3.18.3, 4.6.12, 9.3.2, 11.3.1.4, 13.4.2, 13.5 4.5, 4.7.4, 4.9, 8.3.1, 10.1.2, 11.3.9, 11.3.10 4.1 4.6.9 of Payment Architect, Definition of Architect, Extent of Authority Architect, Limitations of Authority and Responsibility Architect's Additional Services and Expenses Architect's Administration of the Contract Architect's Approvals Architect's Authority to Reject Work Architect's Copyright Architect's Decisions 4.1.1 2.4.1, 3.12.6, 4.6.6, 4.7.2, 5.2, 6.3, 7.1.2, 7.2.1, 7.4, 9.2, 9.3.1, 9.4, 9.5, 9.6.3, 9.8.2, 9.8.3, 9.10.1, 9.10.3, 12.1, 12.2.1, 13.5.1, 13.5.2, 14.2.2, 14.2.4 3.3.3, 3.12.8, 3.12.11, 4.6.5, 4.6.6, 4.6.10, 4.6.12, 4.6.17, 4.6.19, 4.6.20, 4.7.2, 5.2.1, 7.4, 9.6.4 2.4, 9.8.2 11.3.1.1, 12.2.1, 12.2.4, 13.5.2, 13.5.3, 14.2.4 4.6, 4.7.6, 4.7.7, 4.8, 9.4, 9.5 2.4.1, 3.5.1, 3.10.3, 3.12.6, 3.12.8, 3.18.3, 4.6.12 3.5.1, 4.6.10, 12.1.2, 12.2.1 1.3 4.6.10, 4.6.12, 4.6.18, 4.6.19, 4.6.20. 4.7.2, 4.7.6, 4.8.1, 4.8.4, 4.9, 6.3, 8.1.3, 8.3.1, 9.2, 9.4, 9.5.1, 9.8.2, 9.9.1, 10.1.2, AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 3 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 4 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) 13.5.2, 4.6.16, 4.7.6, 14.2.2, 14.2.4 9.4.3, 9.5.1, Architect's Inspections 4.6.5, 4.6.16, 9.8.2, 9.9.2, 4.7.6, 9.4.3, 9.10.1, 13.5 9.8.2, 9.9.2, Asbestos 10.1.2, 9.10.1, 13.5 10.1.3,.10.1.4 Architect's Instructions 4.6.10, Attorneys' Fees 3.18.1, 4.6.12, 7.4.1, 9.10.2, 10.1.4 9.4.3, 12.1, Award of Separate 6.1.1 13.5.2 Contracts Architect's Interpretations 4.6.18, Award of Subcontracts 5.2 4.6.19, 4.7.7 and Other Contracts for Architect's On -Site 4.6.5, 4.6.9, Portions of the Work Observations 4.7.6, 9.4.3, Basic Definitions 1.1 9.5.1, 9.10.1, Bidding Requirements 1.1.1, 1.1.7, 13.5 5.2.1, 11.4.1 Architect's Project 4.6.17 Boiler and Machinery 11.3.2 Representative Insurance Architect's Relationship 1.1.2, 3.2.1, Bonds, Lien 9.10.2 with Contractor 3.2.2, 3.3.3, Bonds, Performance and 7.3.6.4, 3.5.1, 3.7.3, Payment 9.10.3, 3.11, 3.12.8, 11.3.9, 11.4 3.12.11, 3.16, Building Permit 2.2.3, 3.7.1 3.18, 4.6.6, Capitalization 1.4 4.6.7, 4.6.10, Certificate of Substantial 9.8.2 4.6.12, Completion 4.6.19, 5.2, Certificates for Payment 4.6.8, 4.6.9, 6.2.2, 7.3.4, 9.3.3, 9.4, 9.8.2, 10.1.2, 9.5, 9.6.1, 10.1.4, 9.6.6, 9.7.1, 10.1.5, 9.8.3, 9.10.1, 11.3.7, 12.1, 9.10.3, 13.7, 13.5 14.1.1.3, Architect's Relationship 1.1.2, 2.4.1, 14.2.4 with Construction Manager 3.12.6, Certificates of Inspection, 3.12.11, 3.12.8, 4.6.8, Testing or Approval 13.5.4 4.6.10, Certificates of Insurance 9.3.2, 9.10.2, 4.6.14, 11.1.3 4.6.16, Change Orders 1.1.1, 2.4.1, 4.6.18, 6.3.1, 3.8.2.4, 9.7.1, 9.8, 3.11.1, 9.9.1,9.9.2, 4.6.13, 4.7.3, 9.10.1, 5.2.3, 7.1, 9.10.2, 7.2, 7.3.2, 9.10.3, 8.3.1, 9.3.1.1, 12.2.4, 9.10.3, 13.5.1, 11.3.1.2, 13.5.2, 11.3.4, 13.5.4, 14.2.4 11.3.9, 12.1.2 Architect's Relationship 1.1.2, 4.6.6, Change Orders, Definition 7.2.1 with Subcontractors 4.6.7, 4.6.10, of 5.3.1, Changes 7.1 9.6.3,9.6.4, CHANGES IN THE 3.11, 4.6.13, 11.3.7 WORK 4.6.14, 7, Architect's Representations 9.4.3, 9.5.1, 8.3.1, 9.3.1.1, 9.10.1 10.1.3 Architect's Site Visits 4.6.5, 4.6.9, Claim, Definition of 4.7.1 AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 4 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) Claims and Disputes 4.7, 4.8, 4.9, 10.2.2, 11.1, 6.2.5, 8.3.2, 11.3, 13.1, 9.3.1.2, 9.3.3, 13.5.1, 9.10.4, 10.1.4 13.5.2, 13.6, Claims and Timely 4.9.6 14.1.1, Assertion of Claims 14.2.1.3 Claims for Additional 4.7.6, 4.7.7, Concealed or Unknown 4.7.6 Cost 4.7.9, 6.1.1, Conditions 10.3 Conditions of the Contract 1.1.1, 1.1.7, Claims for Additional 4.6.9, 4.7.6, 6.1.1 Time 4.7.8, 4.7.9, Consent, Written 1.3.1, 3.12.8, 8.3.2 3.14.2, 4.7.4. Claims for Concealed or 4.7.6 4.9.5, 9.3.2, Unknown Conditions 9.8.2, 9.9.1, Claims for Damages 3.18, 4.7.9, 9.10.2, 6.1.1, 6.2.5, 9.10.3, 10.12, 8.3.2, 9.5.1.2, 10.1.3, 10.1.4 11.3.1, Claims Subject to 4.7.2, 4.8.4, 11.3.1.4, Arbitration 4.6.1 11.3.11, 13.2, Cleaning Up 3.15, 6.3 13.4.2 Commencement of 13.7 CONSTRUCTION BY 1.1.4, 6 Statutory Limitation OWNER OR BY OTHER Period CONTRACTORS Commencement of the 2.12 ,2.2.1, Construction Change 7.3.1 Work, Conditions Relating 3.2.1, 3.2.2, Directive, Definition of to 3.7.1, 3.10.1 Construction Change 1.1.1, 4.6.13, 3.12.6, 4.7.7, Directives 7.1, 7.3, 5.2.1, 6.2.2, 9.3.1.1 8.1.2, 8.2.2, Construction Manager 4.2 9.2, 11.1.3, Construction Manager, and 2.2.3 11.3.6, 11.4.1 Building Permits Commencement of the 8.1.2 Construction Manager, 4.7.2 Work, Definition of Claims against Communications, Owner to 2.2.6 Construction Manager, 4.6.7 Architect Communications through Communications, Owner to 2.2.6 Construction Manager, and 3.10.1, 3.10.2 Construction Manager Construction Schedule Communications Construction Manager, 4.2.1 Facilitating Contract Definition of Administration 3.9.1 4.6.7, Construction Manager, and 3.11.1 5.2.1 Documents and Samples at Completion, Conditions 3.11, 3.15, the Site Relating to 4.6.5, 4.6.16, Construction Manager, 3.12.6, 4.7.2, 9.4.2, Extent of Authority 3.12.8, 4.3, 9.8, 9.9.1, 4.6.3, 4.6.11, 9.10, 11.3.5, 7.1.2, 7.2.1, 12.2.2, 13.7.1 7.3.1, 8.3.1, COMPLETION, 9 9.2.1, 9.3.1, PAYMENTS AND 9.4.1, 9.4.3, Completion, Substantial 4.6.16, 9.8.2, 9.8.3, 4.7.5.2, 8.1.1, 9.9.1, 12.1, 8.1.3, 8.2.3, 12.2.1, 9.8, 9.9.1, 12.2.4, 12.2.2, 13.7 14.2.2, 14.2.4 Compliance with Laws 1.3, 3.6, 3.7, Construction Manager, 4.6.6, 4.6.10, 3.13, 4.1.1, Limitations of Authority 13.4.2 AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 5 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) and Responsibility 3.17.1, Construction Manager, and 3.10.3 3.18.1, Submittals 3.18.3, 4.6.3, Construction Manager's 12.2.1, 12.2.4 4.6.4, 4.6.6, Additional Services and 4.6.11, 5.2, Expenses 6.2.1, 6.2.2, Construction Manager's 4.6, 9.4, 9.5 7.1.2, 7.2.1, Administration of the 7.3.4, 7.3.6, Contract 7.3.9, 8.3.1, Construction Manager's 2.4.1, 3.10.3 9.2.1,9.3.1, Approval 9.4.1, 9.4.2, Construction Manager's 4.6.10, 12.2.1 9.4.3, 9.7.1, Authority to Reject Work 9.8.2, 9.9.1, Construction Manager's 7.3.6, 7.3.7, 9.10.1, Decisions 7.3.8, 9.3.1, 9.10.2, 9.4.1, 9.5.1 9.10.3, Construction Manager's 4.6.10, 9.4.3, 10.1.1, Inspections 9.8.2, 9.9.2, 10.1.2, 12.1.1 10.1.5, Construction Manager's 9.5.1 10.2.6, On -Site Observations 11.3.7, 12.1, Construction Manager's 1.1.2, 4.6.8, 13.5.1, Relationship with Architect 4.6.10, 13.5.2, 4.6.11, 13.5.3, 13.5.4 4.6.14, Construction Manager's 2.2.3, 4.6.1, 4.6.16, Relationship with Owner 4.6.2, 10.1.6 4.6.18, 6.3.1, Construction Manager's 9.2.1, 9.4.2, Relationship with Other 9.4.3, 9.51, Contractors and Owner's 4.6.3 9.6.1, 9.6.3, Own Forces 9.8.2, 9.8.3, Construction Manager's 4.6.10, 5.3.1, 9.9.1, 9.10.1, Relationship with 9.6.3, 9.6.4 9.10.2, Subcontractors 9.10.3, Construction Manager's 9.4.3, 9.5.1 11.1.3, Representations 12.2.4, Construction Manager's 9.4.4, 9.5.1 13.5.1, Site Visits 13.5.2, Construction Schedules, 3.10, 4.6.3, 13.5.4, Contractor's 4.6.4 14.2.2, 14.2.4 Contingent Assignment of 5.4 Construction Manager's 3.2.1, 3.2.2 Subcontracts Relationship with 3.3.1, 3.3.3, Continuing Contract 4.7.4 Contractor 3.5.1, 3.7.3, Performance 3.10.1, Contract, Definition of 1.1.2 3.10.2, CONTRACT, 4.7.7, 5.4.1.1, 3.10.3, TERMINATION OR 14 3.11.1, SUSPENSION OF THE 3.12.5, Contract Administration 3.3.3, 4, 9.4, 3.12.6, 9.5 3.12.8, Contract Award and 3.7.1, 3.10, 3.12.9, Execution, Conditions 5.2,9.2, 3.12.10, Relating to 11.1.3, 3.12.11, 11.3.6, 11.4.1 3.13.2, Contract Documents, The 1.1, 1.2, 7 3.14.2, Contract Documents, 1.3, 2.2.5, 5.3 3.15.2, Copies Furnished and Use 3.16.1, of AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 6 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) Contract Documents, 1.1.1 Definition of Contract Performance 4.7.4, 4.9.3 During Arbitration Contract Sum 3.8, 4.7.6, 4.7.7, 4.8.4, 5.2.3, 7.2, 7.3, 9.1, 9.7, 11.3.1, 12.2.4, 12.3, 14.2.4 Contract Sum, Definition 9.1.1 of Contract Time 4.7.6, 4.7.8.1, 4.8.4, 7.2.1.3, 7.3, 8.2.1, 8.3.1, 9.7, 12.1.1 Contract Time, Definition 8.1.1 of CONTRACTOR 3 Contractor, Definition of 3.1.1, 6.1.2 Contractor's Bid 1.1.1 Contractor's 3.10 Construction Schedules Contractor's Employees 3.3.2, 3.4.2, 3.8.1, 3.9, 3.18, 4.6.6, 4.6.10, 8.1.2, 10.2, 10.3, 11.1.1, 14.2.1.1 Contractor's Liability 11.1, 11.3.1.5 Insurance Contractor's Relationship 3.12.5, with Other Contractors and 3.14.2, 4.6.3, Owner's Own Forces 4.6.7, 12.2.5 Contractor's Relationship 1.2.4, 3.3.2, with Subcontractors 3.18.1, 3.18.2, 5.2, 5.3, 5.4, 9.6.2, 11.3.7, 11.3.8, 14.2.1.2 Contractor's Relationship 1.1.2, 3.2.1, with the Architect 3.2.2, 3.3.3, 3.5.1, 3.7.3, 3.10.1, 3.10.3, 3.11.1, 3.12.6, 3.12.8, 3.12.9, 3.16.1, 3.18, 4.6.6, 4.6.7, 4.6.10, 4.6.12, Contractor's Relationship with the Construction Manager 4.6.4, 4.6.6, 5.2, 6.2.1, 6.2.2, 7.1.2, 7.2.1, 7.3.4, 7.3.6, 7.3.9, 8.3.1, 9.2.1, 9.3.1, 9.4.1, 9.4.2, 9.4.3, 9.7.1, 9.8.2, 9.9.1, 9.10.1, 9.10.2, 9.10.3, 10.1.1,10.1.2, 10.1.5, 10.2.6, 11.3.7, 12.1, 13.5.1, 13.5.2, 13.5.3, 13.5.4 Contractor's Representations Contractor's Responsibility for Those Performing the Work Contractor's Review of Contract Documents Contractor's Right to Stop the Work Contractor's Right to Terminate the Contract Contractor's Submittals 4.6.19, 5.2, 6.2.2, 7.3.4, 9.2, 9.3.1, 9.8.2, 9.10.3,10.1.2, 10.1.5, 10.2.6, 11.3.7, 12.1, 13.5 1.1.2, 3.2.1, 3.2.2,3.3.1, 3.3.3, 3.5.1, 3.7.3, 3.7.4, 3.10.1, 3.10.2, 3.10.3, 3.11.1, 3.12.5, 3.12.6, 3.12.8, 3.12.9, 3.12.11, 3.13.2, 3.14.2, 3.15.2, 3.16.1, 3.17.1, 3.18.1, 3.18.3, 4.6.3, 1.2.2, 3.5.1, 3.12.7, 6.2.2, 8.2.1, 9.3.3 3.3.2, 3.18, 4.6.6, 10 1.2.2, 3.2, 3.7.3 9.7 14.1 3.10, 3.11, 3.12, 4.6.12, 5.2.1, 5.2.3, 7.3.6, 9.2, 9.3.1, 9.8.2, 9.9.1, 9.10.2, AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 7 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, $ may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) 9.10.3, 9.5.1.6, 9.7 10.1.2, 11.4.2 Date of Commencement of 8.1.2 Contractor's 3.9, 10.2.6 the Work, Definition of Superintendent Date of Substantial 8.1.3 Contractor's Supervision 1.2.4, 3.3, Completion, Definition of and Construction 3.4, 4.6.6, Day, Definition of 8.1.4 Procedures 8.2.2, 8.2.3, Decisions of the Architect 4.6, 4.7, 6.3, 10 8.1.3, 8.3.1, Contractual Liability 11.1.1.7, 9.2, 9.4, Insurance 11.2.1, 9.5.1, 9.8.2, 11.3.1.5 9.9.1, 10.1.2, Coordination and 1.2.2, 1.2.4, 13.5.2, Correlation 3.3.1, 3.10, 14.2.2, 14.2.4 3.12.7, 6.2.1 Decisions of the 4.3, 7.3.6, Copies Furnished of 1.3, 2.2.5, Construction Manager 7.3.7, 7.3.8, Drawings and 3.11 9.3.1, 9.4.1, Specifications 9.4.3, 9.5.1 Correction of Work 2.3, 2.4, Decisions to Withhold 9.5, 9.7, 3.2.1, 4.6.1, Certification 14.1.1.3 9.8.2, 9.9.1, Defective or 12.1.2, 12.2, Nonconforming Work, 13.7.1.3 Acceptance, Cost, Definition of 7.3.6 Rejection and Correction of 2.3, 2.4, Costs 2.4, 3.2.1, 3.5.1, 4.6.1, 3.7.4, 3.8.2, 4.6.10, 4.7.5, 3.15.2., 4.7.6, 9.5, 9.8.2, 4.7.7, 4.7.8.1, 9.9.1, 10.2.5, 5.2.3, 6.1.1, 12, 13.7.1.3 6.2.3, 6.3.1, Defective Work, Definition 3.5.1 7.3.3.3, 7.3.6, of 7.3.7, 9.7, Definitions 1.1, 2.1.1, 9.8.2, 9.10.2, 3.1, 3.5.1, 11.3.1.2,11.3. 3.12.1, 1.3, 11.3.4, 3.12.2, 11.3.9, 12.1, 3.12.3, 4.1.1, 12.2.1, 4.2.1, 4.7.1, 12.2.4, 5.1, 6.1.1, 12.2.5, 13.5, 7.2.1, 7.3.1, 14 7.3.6, 8.1, Cutting and Patching 3.14, 6.2.6 9.1, 9.8.1 Damage to Construction of Delays and Extensions of 4.7.1, 4.7.8.1, Owner or Other Time 4.7.8.2, 6.1.1, Contractors 3.14.2, 6.2.4, 6.2.3, 7.2.1, 9.5.1.5, 7.3.1.3, 7.3.4, 10.2.1.2, 7.3.5, 7.3.8, 10.2.5, 10.3, 7.3.9, 8.1.1, 11.1, 11.3, 8.3, 10.3.1, 12.2.5 14.1.1.4 Damage to the Work 3.14.2, 9.9.1, Disputes 4.7, 4.8, 4.9, 10.2.1.2, 6.2.5, 6.3, 10.2.5, 10.3, 7.3.8, 9.3.1.2 11.3 Documents and Samples at 3.11 Damages, Claims for 3.18, 4.6.9, the Site 6.1.1, 6.2.5, Drawings, Definition of 1.1.5 8.3.2, 9.5.1.2, Drawings and 10.1.4 Specifications, Use and Damages for Delay 6.1.1, 8.3.3, Ownership of 1.1.1, 1.3, AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, $ may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 9 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) 2.2.5, 3.11, Fire and Extended 11.3.1.1, 5.3 Coverage Insurance 11.3.5, 11.3.7 Duty to Review Contract 3.2 GENERAL 1 Documents and Field PROVISIONS Conditions Governing Law 13.1 Effective Date of Insurance 8.2.2, 11.1.2 Guarantees (See Warranty Emergencies 4.7.7, 10.3 and Warranties) Employees, Contractor's 3.3.2., 3.4.2, Hazardous Materials 10.1, 10.2.4 3.8.1, 3.9, Identification of Contract 1.2.1 3.18.1, Documents 3.18.2, 4.6.6, Identification of 5.2.1 4.6.10, 8.1.2, Subcontractors and 10.2, 10.3, Suppliers 11.1.1, Indemnification 3.17, 3.18, 14.2.1.1 9.10.2, Equipment, Labor, 1.1.3, 1.1.6, 10.1.4, Materials and 3.4, 3.5.1, 11.3.1.2, 3.8.2, 3.12.2, 11.3.7 3.12.3, Information and Services 2.1.2, 2.2, 3.12.7, Required of the Owner 4.7.4, 6.2.6, 3.12.11, 3.13, 9.3.2, 9.6.1, 3.15.1, 9.6.4, 9.8.3, 4.6.12, 6.2.1, 9.9.2, 9.10.3, 7.3.6, 9.3.2, 10.1.4, 11.2, 9.3.3, 11.3, 11.3, 13.5.1, 12.2.4, 13.5.2 14.1.2, Injury or Damage to 4.7.9 14.2.1, 14.2.2 Person or Property Execution and Progress of 1.2.3, 3.4.1, Inspections 3.3.3, 3.3.4, the Work 3.5.1, 4.6.5, 3.7.1, 4.6.5, 4.6.6, 4.7.4, 4.6.6, 4.6.16, 4.7.8, 6.2.2, 4.7.6, 9.4.3, 7.1.3, 8.2, 9.8.2, 9.9.2, 8.3, 9.5, 9.10.1, 9.9.1, 10.2.3, 12.1.1, 13.5 10.2.4 Instructions to Bidders 1.1.1 Execution, Correlation 1.2, 3.7.1 Instructions to the 3.8.1, 4.6.13, and Intent of the Contractor 5.2.1, 7, 12.1, Contract Documents 13.5.2 Extensions of Time 4.7.1, 4.7.8, Insurance 4.7.9, 6.1.1, 7.2.1.3, 8.3, 7.3.6.4, 9.3.2, 10.3.1 9.8.2, 9.9.1, Failure of Payment by 9.5.1.3, 9.10.2, 11 Contractor 14.2.1.2 Insurance, Boiler and 11.3.2 Failure of Payment by 4.7.7, 9.7, Machinery Owner 14.1.3 Insurance, Contractor's 11.1, Faulty Work (See Liability 11.3.1.13 Defective or Insurance, Effective Date 8.2.2, 11.1.2 Nonconforming Work) of Final Completion and 4.6.1, 4.6.16, Insurance, Loss of Use 11.3.3 Final Payment 4.7.2, 4.7.5, Insurance, Owner's 11.2, 11.3.1.3 9.10, 11.1.2, Liability 11.1.3, Insurance, Property 10.2.5, 11.3 11.3.5, Insurance, Stored Materials 9.3.2, 12.3.1, 13.7 11.3.1.4 Financial Arrangements, 2.2.1 INSURANCE AND 11 Owner's BONDS AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 9 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) Insurance Companies, 9.9.1, 11.3.11 Consent to Partial Occupancy Insurance Companies, 11.3.10 Settlement with Intent of the Contract 1.2.3, 3.12.4, Documents 4.6.10, 4.6.12, 4.6.19, 4.6.20, 7.4 Interest 13.6 Interpretation 1.2.5, 1.4, 1.5, 4.1.1, 4.7.1, 5.1, 6.1.2, 8.1.4 Interpretations, Written 4.6.18, 4.6.19, 4.7.7 Joinder and Consolidation 4.9.5 of Claims Required Judgment on Final 4.9.1, 4.9.4.1, Award 4.9.7 Labor and Materials, 1.1.3, 1.1.6, Equipment 3.4, 3.5.1, 3.8.2, 3.12.2, 3.12.3, 3.12.7, 3.12.11, 3.13, 3.15.1, 4.6.12, 6.2.1, 7.3.6, 9.3.2, 9.3.3, 12.2.4, 14.1.2, 14.2.1, 14.2.2 Labor Disputes 8.3.1 Laws and Regulations 1.3, 3.6, 3.7, 3.13, 4.1.1, 4.9.5, 4.9.7, 9.9.1, 10.2.2, 11.1, 11.3, 13.1, 13.4.1, 13.5.1, 13.5.2, 13.6 Liens 2.1.2, 4.7.2, 4.7.5.1, 8.2.2, 9.3.3, 9.10.2 Limitation on 4.9.5 Consolidation or Joinder Limitations, Statutes of 4.9.4.2, 12.2.6, 13.7 Limitations of Authority 3.3.1, 4.6.12, 4.6.17, 5.2.2, 5.2.4, 7.4, 11.3.10 Limitations of Liability 2.3, 3.2.1, 3.5.1, 3.7.3, 3.12.8, 3.12.11, 3.17, Limitations of Time, General Limitations of Time, Specific Loss of Use Insurance Material Suppliers 3.18, 4.6.10, 4.6.12, 4.6.19, 6.2.2, 9.4.3, 9.6.4, 9.10.4, 10.1.4, 10.2.5, 11.1.2, 11.2.1, 11.3.7, 13.4.2, 13.5.2 2.2.1, 2.2.4, 3.2.1, 3.7.3, 3.8.2, 3.10, 3.12.5, 3.15.1, 4.6.1, 4.6.12, 4.6.18, 4.7.2, 4.7.3, 4.7.4, 4.7.6,.4.7.9, 4.6.4.2, 5.2.1, 5.2.3, 6.2.4, 7.3.4, 7.4, 8.2, 9.2, 9.5, 9.6.2, 9.8, 9.10, 11.1.3, 11.3.1, 11.3.2, 11.3.5, 11.3.6, 12.2.1, 12.2.2, 13.5, 13.7, 14.3 2.1.2, 2.2.1, 2.4, 3.10, 3.11, 3.15.1, 4.6.1, 4.6.18, 4.7, 4.8, 4.9, 5.3, 5.4, 7.3.5, 7.3.9, 8.2, 9.3.1, 9.3.3, 9.4.1, 9.6.1, 9.7, 9.8.2, 9.10.2, 11.1.3, 11.3.6, 11.3.10, 11.3.11, 12.2.2, 12.2.4, 12.2.6, 13.7, 14.1, 14.2.2 11.3.3 1.3.1, 3.12.1, 4.6.7, 4.6.10, 5.2.1, 9.3.1, 9.3.1.2, 9.3.3, AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 1 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) Notice of Testing and Inspections Notice to Proceed Notices, Permits, Fees and Observations, Architect's On -Site Observations, Construction Manager's On -Site Observations, Contractor's Occupancy On -Site Inspections by the Architect On -Site Observations by the Architect On -Site Observations by the Construction Manager Orders, Written Other Contracts and Contractors OWNER Owner, Definition of Owner, Information and Services Required of the Owner's Authority 5.2.1, 5.3, 5.4.1.1, 8.2.2, 9.4.1, 9.5.1, 9.7, 9.10, 10.1.2, 10.2.6, 11.1.3, 11.3, 12.2.2, 12.2.4, 13.3, 13.5.2, 14 13.5.1, 13.5.2 8.2.2 2.2.3, 3.7, 3.13, 7.3.6.4, 10.2.2 4.6.5, 4.6.9, 4.6.10, 4.7.6, 9.4.4, 9.5.1, 9.10.1, 12.1.1, 13.5 9.4.4, 12.1.1 1.2.2, 3.2.2 9.6.6, 9.8.1, 9.9, 11.3.11 4.6.5, 4.6.16, 4.7.6, 9.4.4, 9.8.2, 9.9.2, 9.10.1 4.6.5, 4.6.9, 4.7.6, 9.4.4, 9.5.1, 9.10.1, 13.5 9.4.4, 9.5.1 2.3, 3.9, 4.7.7, 7, 8.2.2, 11.3.9, 12.1, 12.2, 13.5.2, 14.3.1 1.1.4, 3.14.2, 4.6.7, 4.9.5, 6, 11.3.7, 12.1.2, 12.2.5 2 2.1 2.1.2, 2.2, 4.6.2, 4.6.4, 6, 9, 10.1.4, 10.1.6, 11.2, 11.3, 13.5.1, 14.1.1.5, 14.1.3 3.8.1, 5.2.1, 5.2.4, 5.4.1, 7.3.1, 8.2.2, AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) 9.4.3, 9.6.5, 9.10.4 Materials, Hazardous 10.1, 10.2.4 Materials, Labor, 1.1.3, 1.1.6, Equipment and 3.4.1, 3.5.1, 3.8.2, 3.12.2, 3.12.3, 3.12.7, 3.12.11, 3.13, 3.15.1, 4.6.12, 6.2.1, 7.3.6, 9.3.2, 9.3.3, 12.2.4, 14.1.2, 14.2.1, 14.2.2 Means, Methods, Techniques, Sequences and Procedures of Construction 3.3.1, 4.6.6, 4.6.12, 9.4.3 Minor Changes in the 1.1.1, 4.6.13, Work 4.7.7, 7.1, 7.4 MISCELLANEOUS 13 PROVISIONS Modifications, Definition 1.1.1 of Modifications to the 1.1.1, 1.1.2, Contract 3.7.3, 3.11, 4.1.2, 4.6.1, 5.2.3, 7, 8.3.1, 9.7 Mutual Responsibility 6.2 Nonconforming Work, 12.3 Acceptance of Nonconforming Work, 2.3.1, 4.7.5.2, Rejection and Correction of 9.5.2, 9.8.2, 12, 13.7.1.3 Notice 2.3, 2.4, 3.2.1, 3.2.2, 3.7.3, 3.7.4, 3.9, 3.12.8, 3.12.9, 3.17, 4.7, 4.8.4, 4.9, 5.2.1, 5.3, 5.4.1.1, 8.2.2, 9.4.1, 9.5.1, 9.7, 9.10, 10.1.2, 10.2.6, 11.1.3, 11.3, 12.2.2, 12.2.4, 13.3, 13.5.1, 13.5.2, 14, Notice, Written 2.3, 2.4, 3.9, 3.12.8, 3.12.9,4.7, 4.8.4, 4.9, Notice of Testing and Inspections Notice to Proceed Notices, Permits, Fees and Observations, Architect's On -Site Observations, Construction Manager's On -Site Observations, Contractor's Occupancy On -Site Inspections by the Architect On -Site Observations by the Architect On -Site Observations by the Construction Manager Orders, Written Other Contracts and Contractors OWNER Owner, Definition of Owner, Information and Services Required of the Owner's Authority 5.2.1, 5.3, 5.4.1.1, 8.2.2, 9.4.1, 9.5.1, 9.7, 9.10, 10.1.2, 10.2.6, 11.1.3, 11.3, 12.2.2, 12.2.4, 13.3, 13.5.2, 14 13.5.1, 13.5.2 8.2.2 2.2.3, 3.7, 3.13, 7.3.6.4, 10.2.2 4.6.5, 4.6.9, 4.6.10, 4.7.6, 9.4.4, 9.5.1, 9.10.1, 12.1.1, 13.5 9.4.4, 12.1.1 1.2.2, 3.2.2 9.6.6, 9.8.1, 9.9, 11.3.11 4.6.5, 4.6.16, 4.7.6, 9.4.4, 9.8.2, 9.9.2, 9.10.1 4.6.5, 4.6.9, 4.7.6, 9.4.4, 9.5.1, 9.10.1, 13.5 9.4.4, 9.5.1 2.3, 3.9, 4.7.7, 7, 8.2.2, 11.3.9, 12.1, 12.2, 13.5.2, 14.3.1 1.1.4, 3.14.2, 4.6.7, 4.9.5, 6, 11.3.7, 12.1.2, 12.2.5 2 2.1 2.1.2, 2.2, 4.6.2, 4.6.4, 6, 9, 10.1.4, 10.1.6, 11.2, 11.3, 13.5.1, 14.1.1.5, 14.1.3 3.8.1, 5.2.1, 5.2.4, 5.4.1, 7.3.1, 8.2.2, AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) Owner's Financial Capability Owner's Liability Insurance Owner's Loss of Use Insurance Owner's Relationship with Subcontractors Owner's Right to Carry Out the Work Owner's Right to Clean Up Owner's Right to Perform Construction with Own Forces and to Award Other Contracts Owner's Right to Stop the Work Owner's Right to Suspend the Work Owner's Right to Terminate the Contract Ownership and Use of Architect's Drawings, Specifications and Other Documents Partial Occupancy or Use Patching, Cutting and Patents, Royalties and Payment, Applications for Payment, Certificates for Payment, Failure of Payment, Final 9.3.1, 9.3.2, 11.4.1, 12.2.4, 13.5.2, 14.2, 14.3.1 2.2.1, 14.1.1.5 11.2 11.3.3 1.1.2, 5.2.1, 5.4.1, 9.6.4 2.4, 12.2.4, 14.2.2.2 6.3 6.1 2.3, 4.7.7 Payment Bond, Performance Bond and Payments, Progress PAYMENTS AND COMPLETION Payments to Subcontractors MW Performance Bond and Payment Bond Permits, Fees and Notices PERSONS AND 14.3 PROPERTY, PROTECTION OF 14.2 Polychlorinated Biphenyl 1.1.1, 1.3, Product Data, Definition of 2.2.5, 5.3 Product Data and Samples, Shop Drawings Progress and Completion 9.6.6, 9.9, 11.3.11 Progress Payments 3.14, 6.2.6 3.17 4.6.9, 9.2, 9.3, 9.4, Project, Definition of the 9.5.1, 9.8.3, Project Manual, 9.10.1, Definition of the 9.10.3, Project Manuals 9.10.4, 14.2.4 Project Representatives 4.6.9, 4.6.16, Property Insurance 9.3.3, 9.4, PROTECTION OF 9.5, 9.6.1, PERSONS AND 9.6.6, 9.7.1, PROPERTY 9.8.3, 9.10.1, Regulations and Laws 9.10.3, 13.7, 14.1.1.3, 14.2.4 4.7.7, 9.5.1.3, 9.7, 9.10.2, 14.1.1.3, 14.2.1.2 4.6.1, 4.6.16, Rejection of Work 4.7.2, 4.7.5, 9.10, 11.1.2., Releases of Waivers and 11.1.3, Liens 11.3.5, 12.3.1 7.3.6.4, 9.10.3, 11.3.9, 11.4 4.7.4, 9.3, 9.6, 9.8.3, 9.10.3, 13.6, 14.2.3 9,14 5.4.2, 9.5.1.3, 9.6.2, 9.6.3, 9.6.4, 11.3.8, 14.2.1.2 10.1.2, 10.1.3, 10.1.4 7.3.6.4, 9.10.3, 11.3.9, 11.4 2.2.3, 3.7, 3.13, 7.3.6.4, 10.2.2 10 10.1.2, 10.1.3, 10.1.4 3.12.2 3.11, 3.12, 4.2.7 4.6.5, 4.7.4, 8.2 4.7.4, 9.3, 9.6, 9.8.3, 9.10.3, 13.6, 14.2.3 1.1.4 1.1.7 2.2.5 4.6.17 10.2.5, 11.3 10 1.3, 3.6, 3.7, 3.13, 4.1.1, 4.9.7, 10.2.2, 11.1, 11.3, 13.1, 13.4, 13.5.1, 13.5.2, 13.6, 14 3.5.1, 4.6.10, 12.2. 9.10.2 AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 12 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) Representations 1.2.2, 3.5.1, Contractors 3.12.7, 6.2.2, Shop Drawings, Definition 3.12.1 8.2.1, 9.3.3, of 9.4.3, 9.5.1, Shop Drawings, Product 3.11, 3.12, 9.8.2, 9.10.1 Data and Samples 4.6.11, Representatives 2.1.1, 3.1.1, 4.6.12, 4.6.15 3.9, 4.1.1, Site, Use of 3.13, 6.1.1, 4.6.1, 4.6.17, 6.2.1 5.1.1, 5.1.2, Site Inspections 1.2.2, 3.3.4, 13.2.1 4.6.5, 4.6.16, Resolution of Claims and 4.8, 4.9 4.7.6, 9.8.2, Disputes 9.10.1, 13.5 Responsibility for Those 3.3.2, 4.6.6, Site Visits, Architect's 4.6.5, 4.6.9, Performing the Work 6.2., 10 4.7.6, 9.4, Retainage 9.3.1, 9.6.2, 9.5.1, 9.8.2, 9.8.3, 9.9.1, 9.9.2, 9.10.1, 9.10.2, 9.10.3 13.5 Review of Contract 1.2.2, 3.2, Special Inspections and 4.6.10, Documents and Field 3.7.3, 3.12.7 Testing 12.2.1, 13.5 Conditions by Contractor Specifications, Definition 1.1.6 Review of Contractor's of the Submittals by Specifications, The 1.1.1, Owner, Construction 3.10.1, 1.1.7, 1.2.4, Manager and Architect 3.10.3, 3.11, 1.3, 3.11 3.12, 4.6.12. Statute of Limitations 4.9.4.2, 4.6.16, 5.2.1, 12.2.6, 13.7 5.2.3, 9.2, Stopping the Work 2.3, 4.7.7, 9.8.2 9.7, 10.1.2, Review of Shop Drawings, 3.12.5 10.3, 14.1 Product Data and Samples Stored Materials 6.2.1, 9.3.2, by Contractor 10.2.1.2, Rights and Remedies 1.1.2, 2.3, 11.3.1.4, 2.4, 3.5.1, 12.2.4 3.15.2, Subcontractor, Definition 5.1.1 4.6.10, 4.7.6, of 4.9, 5.3, 6.1, SUBCONTRACTORS 5 6.3, 7.3.1, Subcontractors, Work by 1.2.4, 3.3.2, 8.3.1, 9.5.1, 3.12.1, 4.6.6, 9.7, 10.2.5, 4.6.10, 5.3, 10.3, 12.2.2, 5.4 12. 2.4, 13.4, Subcontractual Relations 5.3, 5.4, 14 9.3.1.2, 9.6.2, Royalties and Patents 3.17 9.6.3, 9.6.4, Rules and Notices for 4.9.2 10.2.1, Arbitration 11.3.7, Safety of Persons and 10.2 11.3.8, Property 14.1.1, Safety Precautions and 4.6.6, 4.6.12, 14.2.1.2, Programs 10.1 14.1.3 Samples, Definition of 3.12.3 Submittals 1.3, 3.2.3, Samples, Shop Drawings, 3.11, 3.12, 3.10, 3.11, Product Data and 4.6.12 3.12, 4.6.12, Samples at the Site, 3.11 5.2.1, 5.2.3, Documents and 7.3.6, 9.2, Schedule of Values 9.2, 9.3.1 9.3.1, 9.8.2, Schedules, Construction 3.10 9.9.1, 9.10.2, Separate Contracts and 1.1.4 9.10.3, 11.1.3 AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 3 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) Subrogation, Waivers of 6.1.1, 11.3.5, Extensions of 8.3 11.3.7 Time Limits, Specific 2.1.2, 2.2.1, Substantial Completion 4.6.16, 8.1.1, 2.4, 3.10, 8.1.3, 8.2.3, 4.6.18, 4.7, 9.8, 9.9.1, 4.8.1, 4.8.3, 12.2.1, 4.8.4, 4.9.1, 12.2.2, 13.7 4.9.4.1, Substantial Completion, 9.8.1 4.9.4.2, 5.3, Definition of 5.4, 7.3.5, Substitution of 5.2.3, 5.2.4 7.3.9, 8.2, Subcontractors 9.2, 9.3.1, Substitution of Architect 4.4 9.3.3, 9.4.1, Substitution of 4.4 9.6.1, 9.7, Construction Manager 9.8.2, 9.10.2, Substitutions of Materials 3.5.1 11.1.3, Sub - subcontractor, 5.1.2 11.3.6, Definition of 11.3.10, Subsurface Conditions 4.7.6 11.3.11, Successors and Assigns 13.2 12.2.2, Superintendent 3.9, 10.2.6 12.2.4, Supervision and 1.2.4, 3.3, 12.2.6, 13.7, Construction Procedures 3.4, 4.6.6, 14 4.7.4, 6.2.4, Time Limits on Claims 4.7.2, 4.7.3, 7.1.3, 7.3.4, 4.7.6, 4.7.9, 8.2, 8.3.1, 10, 4.8, 4.9 12,14 Title to Work 9.3.2, 9.3.3 Surety 4.8.1, 4.8.4, UNCOVERING AND 12 5.4.1.2, CORRECTION OF 9.10.2, WORK 9.10.3, 14.2.2 Uncovering of Work 12.1 Surety, Consent of 9.10.2, 9.10.3 Unforeseen Conditions 4.7.6, 8.3.1, Surveys 2.2.2, 3.18.3 10.1 Suspension by the Owner 14.3 Unit Prices 7.1.4, 7.3.3.2 for Convenience Use of Documents 1.1.1, 1.3, Suspension of the Work 4.7.7, 5.4.2, 2.2.5, 3.12.7, 14.1.1.4, 14.3 5.3 Suspension or Termination 4.7.7, 5.4.1.1, Use of Site 3.13, 6.1.1, of the Contract 14 6.2.1 Taxes 3.6, 7.3.6.4 Values, Schedule of 9.2, 9.3.1 Termination by the 14.1 Waiver of Claims: Final 4.7.5, 4.9.1, Contractor Payment 9.10.3 Termination by the 5.4.1.1, 14.2 Waiver of Claims by the 13.4.2 Owner for Cause Architect Termination of the 4.4 Waiver of Claims by the 9.10.4, Architect Contractor 11.3.7, 13.4.2 Termination of the 4.4 Waiver of Claims by the 4.7.5, 4.9.1, Construction Manager Owner 9.9.3, 9.10.3, Termination of the 14.2.2 11.3.3, Contractor 11.3.5, TERMINATION OR 14 11.3.7, 13.4.2 SUSPENSION OF THE Waiver of Liens 9.10.2 CONTRACT Waivers of Subrogation 6.1.1, 11.3.5, Tests and Inspections 3.3.3, 4.6.10, 11.3.7 4.6.16, 9.4.3, Warranty and 3.5, 4.6.16, 12.2.1, 13.5 Warranties 4.7.5, 9.3.3, TIME 8 9.8.2, 9.9.1, Time, Delays and 4.7.8, 7.2.1, 12.2.2, AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 14 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) Written Orders 5.2.1, 5.3, 5.4.1.1, 8.2.2, 9.4, 9.5.1, 9.7, 9.10, 10.1.2, 10.2.6, 11.1.3, 11.3, 12.2.2, 12.2.4, 13.3, 13.5.2, 14 2.3, 3.9, 4.7.7, 8.2.2, 11.3.9, 12.1, 12.2, 13.5.2, 14.3.1 AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 5 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) 13.7.1.3 Weather Delays 4.7.8.2 When Arbitration May 4.9.4 Be Demanded Work, Definition of 1.1.3 Written Consent 1.3.1, 3.12.8, 3.14.2, 4.7.4, 4.9.5, 9.3.2, 9.8.2, 9.9.1, 9.10.2, 9.10.3, 10.1.2, 10.1.3, 11.3.1, 11.3.1.4, 11.3.11, 13.2, 13.4.2 Written Interpretations 4.6.18, 4.6.19, 4.7.7 Written Notice 2.3, 2.4, 3.9, 3.12.8, 3.12.9, 4.7.1, 4.7.6, 4.7.9, 4.8.4, 4.9.4.1, Written Orders 5.2.1, 5.3, 5.4.1.1, 8.2.2, 9.4, 9.5.1, 9.7, 9.10, 10.1.2, 10.2.6, 11.1.3, 11.3, 12.2.2, 12.2.4, 13.3, 13.5.2, 14 2.3, 3.9, 4.7.7, 8.2.2, 11.3.9, 12.1, 12.2, 13.5.2, 14.3.1 AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 5 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) ARTICLE 1 GENERAL PROVISIONS § 1.1 BASIC DEFINITIONS § 1.1.1 THE CONTRACT DOCUMENTS The Contract Documents consist of the Agreement between Owner and Contractor (hereinafter the Agreement), Conditions of the Contract (General, Supplementary and other Conditions), Drawings, Specifications, addenda issued prior to execution of the Contract, other documents listed in the Agreement and Modifications issued after execution of the Contract. A Modification is (1) a written amendment to the Contract signed by both parties, (2) a Change Order, (3) a Construction Change Directive or (4) a written order for a minor change in the Work issued by the Architect. Unless specifically enumerated in the Agreement, the Contract Documents do not include other documents such as bidding requirements (advertisement or invitation to bid, Instructions to Bidders, sample forms, the Contractor's bid or portions of addenda relating to bidding requirements). § 1.1.2 THE CONTRACT The Contract Documents form the Contract for Construction. The Contract represents the entire and integrated agreement between the parties hereto and supersedes prior negotiations, representations or agreements, either written or oral. The Contract may be amended or modified only by a Modification. The Contract Documents shall not be construed to create a contractual relationship of any kind (1) between the Architect and Contractor, (2) between the Construction Manager and Contractor, (3) between the Architect and Construction Manager, (4) between the Owner and a Subcontractor or Sub - subcontractor or (5) between any persons or entities other than the Owner and Contractor. The Construction Manager and Architect shall, however, be entitled to performance and enforcement of obligations under the Contract intended to facilitate performance of their duties. § 1.1.3 THE WORK The term "Work" means the construction and services required by the Contract Documents, whether completed or partially completed, and includes all other labor, materials, equipment and services provided or to be provided by the Contractor to fulfill the Contractor's obligations. The Work may constitute the whole or a part of the Project. § 1.1.4 THE PROJECT The Project is the total construction of which the Work performed under the Contract Documents may be the whole or a part and which may include construction by other Contractors and by the Owner's own forces including persons or entities under separate contracts not administered by the Construction Manager. § 1.1.5 THE DRAWINGS The Drawings are the graphic and pictorial portions of the Contract Documents, wherever located and whenever issued, showing the design, location and dimensions of the Work, generally including plans, elevations, sections, details, schedules and diagrams. § 1.1.6 THE SPECIFICATIONS The Specifications are that portion of the Contract Documents consisting of the written requirements for materials, equipment, construction systems, standards and workmanship for the Work, and performance of related services. § 1.1.7 THE PROJECT MANUAL The Project Manual is the volume usually assembled for the Work which may include the bidding requirements, sample forms, Conditions of the Contract and Specifications. § 1.2 EXECUTION, CORRELATION AND INTENT § 1.2.1 The Contract Documents shall be signed by the Owner and Contractor as provided in the Agreement. If either the Owner or Contractor or both do not sign all the Contract Documents, the Architect shall identify such unsigned Documents upon request. § 1.2.2 Execution of the Contract by the Contractor is a representation that the Contractor has visited the site, become familiar with local conditions under which the Work is to be performed and correlated personal observations with requirements of the Contract Documents. § 1.2.3 The intent of the Contract Documents is to include all items necessary for the proper execution and completion of the Work by the Contractor. The Contract Documents are complementary, and what is required by one shall be as binding as if required by all; performance by the Contractor shall be required only to the extent AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 6 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) consistent with the Contract Documents and reasonably inferable from them as being necessary to produce the intended results. § 1.2.4 Organization of the Specifications into divisions, sections and articles, and arrangement of Drawings shall not control the Contractor in dividing the Work among Subcontractors or in establishing the extent of Work to be performed by any trade. § 1.2.5 Unless otherwise stated in the Contract Documents, words which have well -known technical or construction industry meanings are used in the Contract Documents in accordance with such recognized meanings. § 1.3 OWNERSHIP AND USE OF ARCHITECT'S DRAWINGS, SPECIFICATIONS AND OTHER DOCUMENTS § 1.3.1 The Drawings, Specifications and other documents prepared by the Architect are instruments of the Architect's service through which the Work to be executed by the Contractor is described. The Contractor may retain one contract record set. Neither the Contractor nor any Subcontractor, Sub - subcontractor or material or equipment supplier shall own or claim a copyright in the Drawings, Specifications and other documents prepared by the Architect, and unless otherwise indicated the Architect shall be deemed the author of them and will retain all common law, statutory and other reserved rights, in addition to the copyright. All copies of them, except the Contractor's record set, shall be returned or suitably accounted for to the Architect, on request, upon completion of the Work. The Drawings, Specifications and other documents prepared by the Architect, and copies thereof furnished to the Contractor, are for use solely with respect to this Project. They are not to be used by the Contractor or any Subcontractor, Sub - subcontractor or material or equipment supplier on other projects or for additions to this Project outside the scope of the Work without the specific written consent of the Owner and Architect. The Contractor, Subcontractors, Sub - subcontractors and material or equipment suppliers are granted a limited license to use and reproduce applicable portions of the Drawings, Specifications and other documents prepared by the Architect appropriate to and for use in the execution of their Work under the Contract Documents. All copies made under this license shall bear the statutory copyright notice, if any, shown on the Drawings, Specifications and other documents prepared by the Architect. Submittal or distribution to meet official regulatory requirements or for other purposes in connection with this Project is not to be construed as publication in derogation of the Architect's copyright or other reserved rights. § 1.4 CAPITALIZATION § 1.4.1 Terms capitalized in these General Conditions include those which are (1) specifically defined, (2) the titles of numbered articles or (3) the titles of other documents published by the American Institute of Architects. § 1.5 INTERPRETATION § 1.5.1 In the interest of brevity the Contract Documents frequently omit modifying words such as "all" and "any" and articles such as "the" and "an," but the fact that a modifier or an article is absent from one statement and appears in another is not intended to affect the interpretation of either statement. ARTICLE 2 OWNER § 2.1 DEFINITION § 2.1.1 The Owner is the person or entity identified as such in the Agreement and is referred to throughout the Contract Documents as if singular in number. The term "Owner" means the Owner or the Owner's authorized representative. § 2.1.2 It is distinctly understood that by virtue of this Contract, no mechanic, contactor, materialman, artisan, laborer, or subcontractor, whether skilled or unskilled, shall fiwni h tR the rem e ver in any manner have, claim, or acquire any lien upon the Ga project of whatever nature or kind so erected or to evaluate, give natiee be erected by virtue of this Contract, nor upon any of the feeefd legal title te the land upon which said improvements are so erected, built or situated, such property being public property belon in to as the s a nd the 0, e f': Merest then -ein at the tifne a political subdivision of e*eet ition of the Agr-eei�neat and, within five Elays af4er- any State of . Texas. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 17 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 2.2 INFORMATION AND SERVICES REQUIRED OF THE OWNER § 2.2.1 The Owner shall, at the request of the Contractor, prior to execution of the Agreement and promptly from time to time thereafter, furnish to the Contractor reasonable evidence that financial arrangements have been made to fulfill the Owner's obligations under the Contract. [Note: Unless such reasonable evidence were furnished on request prior to the execution of the Agreement, the prospective contractor would not be required to execute the Agreement or to commence the Work.] § 2.2.2 The Owner shall furnish surveys describing physical characteristics, legal hw&atiafis limitations, and utility locations for the site of the Project, and a legal description of the site. Owner does not guarantee the accuracy of the survey as describing the site of the Project and Contractor should determine the sufficiency of same before beginning the work. The Owner does not guarantee the utility lines to be in the exact locations as shown on plans and surveys. Contractor shall verify with the utilities the location of utility lines. Any water, gas or sewer line, telephone, telegraph or electric wire, or cable broken or cut by the Contractor or any of his workmen or subcontractors , shall be replaced by the Contractor at his own expense, or by the responsible subcontractor at its own expense and will not be paid for by the Owner. Repairs shall be made immediately and no other work shall be done until breaks or damages have been repaired and service restored. Any delay Cause by the cut or break shall be solely attributed to the Contractor. § 2.2.3 Except for permits and fees which are the responsibility of the Contractor under the Contract Documents, the Owner shall secure and pay for necessary approvals, easements, assessments and charges required for construction, use or occupancy of permanent structures or for permanent changes in existing facilities. Unless otherwise provided under the Contract Documents, the Owner, through the Construction Manager, shall secure and pay for the building permit. § 2.2.4 Information or services under the Owner's control shall be furnished by the Owner with reasonable promptness to avoid delay in orderly progress of the Work. § 2.2.5 Unless otherwise provided in the Contract Documents, the Contractor will be furnished, free of charge, such copies of Drawings and Project Manuals as are reasonably necessary for execution of the Work. § 2.2.6 The Owner shall forward all communications to the Contractor through the Construction Manager and shall contemporaneously provide the same communications to the Architect. § 2.2.7 The foregoing are in addition to other duties and responsibilities of the Owner enumerated herein and especially those in respect to Article 6 (Construction by Owner or by Other Contractors), Article 9 (Payments and Completion) and Article 11 (Insurance and Bonds). § 2.3 OWNER'S RIGHT TO STOP THE WORK § 2.3.1 If the Contractor fails to correct Work which is not in accordance with the requirements of the Contract Documents as required by Section 12.2 or persistently fails to carry out Work in accordance with the Contract Documents, the Owner, by written order signed personally or by an agent specifically so empowered by the Owner in writing, may order the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, the right of the Owner to stop the Work shall not give rise to a duty on the part of the Owner to exercise this right for the benefit of the Contractor or any other person or entity. § 2.4 OWNER'S RIGHT TO CARRY OUT THE WORK § 2.4.1 If the Contractor defaults or neglects to carry out the Work in accordance with the Contract Documents and fails within a seven -day period after receipt of written notice from the Owner to commence and continue correction of such default or neglect with diligence and promptness, the Owner may after such seven -day period give the Contractor a second written notice to correct such deficiencies within a second seven -day period. If the Contractor within such second seven -day period after receipt of such second notice fails to commence and continue to correct any deficiencies, the Owner may, without prejudice to other remedies the Owner may have, correct such deficiencies. In such case an appropriate Change Order shall be issued deducting from payments then or thereafter due the Contractor the cost of correcting such deficiencies, including compensation for the Construction Manager's and Architect's and their respective consultants' additional services and expenses made necessary by such default, neglect or failure. Such action by the Owner and amounts charged to the Contractor are both subject to prior AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, $ may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) approval of the Architect, after consultation with the Construction Manager. If payments then or thereafter due the Contractor are not sufficient to cover such amounts, the Contractor shall pay the difference to the Owner. ARTICLE 3 CONTRACTOR § 3.1 DEFINITION § 3.1.1 The Contractor is the person or entity identified as such in the Agreement and is referred to throughout this Agreement as if singular in number. The term "Contractor" means the Contractor or the Contractor's authorized representative. § 3.1.2 The plural term "Contractors" refers to persons or entities who perform construction under Conditions of the Contract that are administered by the Construction Manager, and that are identical or substantially similar to these Conditions. § 3.2 REVIEW OF CONTRACT DOCUMENTS AND FIELD CONDITIONS BY CONTRACTOR § 3.2.1 The Contractor shall carefully study and compare the Contract Documents with each other and with information furnished by the Owner pursuant to Section 2.2.2 and shall at once report to the Construction Manager and Architect errors, inconsistencies or omissions discovered. The Contractor shall not be liable to the Owner, Construction Manager or Architect for damage resulting from errors, inconsistencies or omissions in the Contract Documents unless the Contractor recognized such error, inconsistency or omission and knowingly failed to report it to the Construction Manager and Architect. If the Contractor performs any construction activity knowing it involves a recognized error, inconsistency or omission in the Contract Documents without such notice to the Construction Manager and Architect, the Contractor shall assume appropriate responsibility for such performance and shall bear an appropriate amount of the attributable costs for correction. § 3.2.2 The Contractor shall take field measurements and verify field conditions and shall carefully compare such field measurements and conditions and other information known to the Contractor with the Contract Documents before commencing activities. Errors, inconsistencies or omissions discovered shall be reported to the Construction Manager and Architect at once. § 3.2.3 The Contractor shall perform the Work in accordance with the Contract Documents and submittals approved pursuant to Section 3.12. § 3.3 SUPERVISION AND CONSTRUCTION PROCEDURES § 3.3.1 The Contractor shall supervise and direct the Work, using the Contractor's best skill and attention. The Contractor shall be solely responsible for and have control over construction means, methods, techniques, sequences and procedures and for coordinating all portions of the Work under this Contract, subject to overall coordination of the Construction Manager as provided in Sections 4.6.3 and 4.6.4. § 3.3.2 The Contractor shall be responsible to the Owner for acts and omissions of the Contractor's employees, Subcontractors and their agents and employees, and other persons performing portions of the Work under a contract with the Contractor. § 3.3.3 The Contractor shall not be relieved of obligations to perform the Work in accordance with the Contract Documents either by activities or duties of the Construction Manager or Architect in their administration of the Contract, or by tests, inspections or approvals required or performed by persons other than the Contractor. § 3.3.4 The Contractor shall inspect portions of the Project related to the Contractor's Work in order to determine that such portions are in proper condition to receive subsequent Work. § 3.4 LABOR AND MATERIALS § 3.4.1 Unless otherwise provided in the Contract Documents, the Contractor shall provide and pay for labor, materials, equipment, tools, construction equipment and machinery, water, heat, utilities, transportation, and other facilities and services necessary for proper execution and completion of the Work, whether temporary or permanent and whether or not incorporated or to be incorporated in the Work. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 19 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 3.4.2 The Contractor shall enforce strict discipline and good order among the Contractor's employees and other persons carrying out the Contract. The Contractor shall not permit employment of unfit persons or persons not skilled in tasks assigned to them. 3.4.3 Prevailing Wages Attention is called to the Government Code, Chapter 2258, "Prevailing Wages Rates ". Among other things, this article provides that it shall be mandatory upon the Contractor and upon any Subcontractor under him to pay no less than the prevailing rates of per diem wages in the locality at the time of construction to all laborers, workmen, and mechanics employ them in the execution of the Contract. No claims for additional compensation shall be considered by the Owner because of payments of wage rates in excess of the applicable rate provided herein. 4 3.4.4 In accordance therewith, the Owner has established a scale of prevailing wages which is incorporated in the project specifications, and not less than this established scale must be paid in the project. Any workers not included in the schedule shall be properly classified and paid not less than the rate of wages prevailing the locality of the work at the time of construction. 3.4.5 Owner reserves the right to receive and review payroll records, payments records, and earnings statements of employees of Contractor, and of Contractor's Subcontractors, and of Sub - Subcontractors. § 3.5 WARRANTY § 3.5.1 The Contractor warrants to the Owner, Construction Manager and Architect that materials and equipment furnished under the Contract will be of good quality and new unless otherwise required or permitted by the Contract Documents, that the Work will be free from defects not inherent in the quality required or permitted, and that the Work will conform with the requirements of the Contract Documents. Work not conforming to these requirements, including substitutions not properly approved and authorized, may be considered defective. The Contractor's warranty excludes remedy for damage or defect caused by abuse, modifications not executed by the Contractor, improper or insufficient maintenance, improper operation, or normal wear and tear under normal usage. If required by the Construction Manager or Architect, the Contractor shall furnish satisfactory evidence as to the kind and quality of materials and equipment. 3.5.2 Except where otherwise stipulated in the Contract Documents, the Contractor shall, as per its Contract, warranty all materials and workmanship furnished under this Contract for a period of one (1) year after the date of Substantial Completion and shall repair and make good, without expense to the Owner, any and all defects in his work which may develop within that time. 3.5.3 All required warranties on equipment, machinery, materials, or components shall be submitted to the Architect on the manufacturer's or supplier's approved forms at the time of Substantial Completion. 4 3.5.4 If the Project involves work on more than one building for the Owner, the work in each building, or approved phase of each building, shall have its own, separate, and independent date of substantial completion and final completion. Contractor shall maintain a complete and accurate schedule of the dates of Substantial Completion, dates upon which the one —year warranty on each phase or building, which is substantially completed, will expire, and date of Final Completion. Contractor agrees es to provide notice of the warranty expiration date to the Owner and Architect at least one month prior to the expiration of the one year warranty period on each building or each phase of the building, which has been substantially completed. Prior to termination of the one year warranty period, Contractor shall accompany Owner and Architect on re- inspection of the work and be responsible for correcting any warranty items which are observed or reported during the warranty period. Contractor shall prosecute such warranty work without interruption until accepted by Owner and Architect, even though such work should extend beyond the warranty period. If Contractor fails to provide notice of the expiration of one year period at least one month prior to the expiration date, Contractor's warranty obligations described in this paragraph shall continue until such inspection is conducted and any deficiencies found corrected. 4 3.5.5 Contractor shall certify that the project has been constructed in general accordance with the Contract Documents. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 20 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 3.6 TAXES § 3.6.1 This project is eligible for exemption from the State Sales Tax on materials incorporated in the Project, provided that Contractor fulfills the requirements of State Tax Laws. For the purpose of establishing exemption, it is understood and agreed that contractor will be required to segregate materials and labor costs at the time a Contract is awarded, and will accept an exemption certificate from Owner. The Contractor shall pay sales us and ~'�es-any Taxes otherwise assessed because of Contractor's failure to comply with the requirements of State Law to qualify for the . tax exemption. § 3.7 PERMITS, FEES AND NOTICES § 3.7.1 Unless otherwise provided in the Contract Documents, the Owner shall secure and pay for the building permit and the Contractor shall secure and pay for all other permits and governmental fees, licenses and inspections necessary for proper execution and completion of the Work which are customarily secured after execution of the Contract and which are legally required when bids are received or negotiations concluded. § 3.7.2 The Contractor shall comply with and give notices required by laws, ordinances, rules and regulations and lawful orders of public authorities bearing on performance of the Work. § 3.7.3 It is not the Contractor's responsibility to ascertain that the Contract Documents are in accordance with applicable laws, statutes, ordinances, building codes, and rules and regulations. However, if the Contractor observes that portions of the Contract Documents are at variance therewith, the Contractor shall promptly notify the Construction Manager, Architect and Owner in writing, and necessary changes shall be accomplished by appropriate Modification. § 3.7.4 If the Contractor performs Work knowing it to be contrary to laws, statutes, ordinances, building codes, and rules and regulations without such notice to the Construction Manager, Architect and Owner, the Contractor shall assume full responsibility for such Work and shall bear the attributable costs. § 3.8 ALLOWANCES § 3.8.1 The Contractor shall include in the Contract Sum all allowances stated in the Contract Documents. Items covered by allowances shall be supplied for such amounts and by such persons or entities as the Owner may direct, but the Contractor shall not be required to employ persons or entities against which the Contractor makes reasonable objection. § 3.8.2 Unless otherwise provided in the Contract Documents: .1 materials and equipment under an allowance shall be selected promptly by the Owner to avoid delay in the Work; .2 allowances shall cover the cost to the Contractor of materials and equipment delivered at the site and all required taxes, less applicable trade discounts; .3 Contractor's costs for unloading and handling at the site, labor, installation costs, overhead, profit and other expenses contemplated for stated allowance amounts shall be included in the Contract Sum and not in the allowances; .4 whenever costs are more than or less than allowances, the Contract Sum shall be adjusted accordingly by Change Order. The amount of the Change Order shall reflect (1) the difference between actual costs and the allowances under Section 3.8.2.2 and (2) changes in Contractor's costs under Section 3.8.2.3. § 3.9 SUPERINTENDENT § 3.9.1 The Contractor shall employ a competent superintendent and necessary assistants who shall be in attendance at the Project site during performance of the Work. The superintendent shall represent the Contractor, and communications given to the superintendent shall be as binding as if given to the Contractor. Important communications shall be confirmed in writing. Other communications shall be similarly confirmed on written request in each case. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 21 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 3.10 CONTRACTOR'S CONSTRUCTION SCHEDULE § 3.10.1 The Contractor, promptly after being awarded the Contract, shall prepare and submit for the Owner's and Architect's information and the Construction Manager's approval a Contractor's Construction Schedule for the Work. Such schedule shall not exceed time limits current under the Contract Documents, shall be revised at appropriate intervals as required by the conditions of the Work and Project, shall be related to the entire Project construction schedule to the extent required by the Contract Documents, and shall provide for expeditious and practicable execution of the Work. § 3.10.2 The Contractor shall cooperate with the Construction Manager in scheduling and performing the Contractor's Work to avoid conflict, delay in or interference with the Work of other Contractors or the construction or operations of the Owner's own forces. § 3.10.3 The Contractor shall prepare and keep current, for the Construction Manager's and Architect's approval, a schedule of submittals which is coordinated with the Contractor's Construction Schedule and allows the Construction Manager and Architect reasonable time to review submittals. § 3.10.4 The Contractor shall conform to the most recent schedules. § 3.11 DOCUMENTS AND SAMPLES AT THE SITE § 3.11.1 The Contractor shall maintain at the site for the Owner one record copy of the Drawings, Specifications, addenda, Change Orders and other Modifications, in good order and marked currently to record changes and selections made during construction, and in addition approved Shop Drawings, Product Data, Samples and similar required submittals. These shall be available to the Construction Manager and Architect and shall be delivered to the Construction Manager for submittal to the Owner upon completion of the Work. 4 3.11.2 Contractor shall at all times maintain job records, including, but not limited to, invoices, payment records, payroll records, daily reports, logs, dairies, and job meeting minutes, applicable to the project. Contractor shall make such reports and records available to inspection by the Owner, Architect, or their respective agents, within five (5) working days of request by Owner, Architect, or their respective a eg nts. § 3.12 SHOP DRAWINGS, PRODUCT DATA AND SAMPLES § 3.12.1 Shop Drawings are drawings, diagrams, schedules and other data specially prepared for the Work by the Contractor or a Subcontractor, Sub - subcontractor, manufacturer, supplier or distributor to illustrate some portion of the Work. § 3.12.2 Product Data are illustrations, standard schedules, performance charts, instructions, brochures, diagrams and other information furnished by the Contractor to illustrate materials or equipment for some portion of the Work. § 3.12.3 Samples are physical examples which illustrate materials, equipment or workmanship and establish standards by which the Work will be judged. § 3.12.4 Shop Drawings, Product Data, Samples and similar submittals are not Contract Documents. The purpose of their submittal is to demonstrate for those portions of the Work for which submittals are required the way the Contractor proposes to conform to the information given and the design concept expressed in the Contract Documents. Review by the Architect is subject to the limitations of Section 4.6.12. § 3.12.5 The Contractor shall review, approve and submit to the Construction Manager, in accordance with the schedule and sequence approved by the Construction Manager, Shop Drawings, Product Data, Samples and similar submittals required by the Contract Documents. The Contractor shall cooperate with the Construction Manager in the coordination of the Contractor's Shop Drawings, Product Data, Samples and similar submittals with related documents submitted by other Contractors. Submittals made by the Contractor which are not required by the Contract Documents may be returned without action. § 3.12.6 The Contractor shall perform no portion of the Work requiring submittal and review of Shop Drawings, Product Data, Samples or similar submittals until the respective submittal has been approved by the Construction Manager and Architect. Such Work shall be in accordance with approved submittals. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 22 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 3.12.7 By approving and submitting Shop Drawings, Product Data, Samples and similar submittals, the Contractor represents that the Contractor has determined and verified materials, field measurements and field construction criteria related thereto, or will do so, and has checked and coordinated the information contained within such submittals with the requirements of the Work and of the Contract Documents. § 3.12.8 The Contractor shall not be relieved of responsibility for deviations from requirements of the Contract Documents by the Construction Manager's and Architect's approval of Shop Drawings, Product Data, Samples or similar submittals unless the Contractor has specifically informed the Construction Manager and Architect in writing of such deviation at the time of submittal and the Construction Manager and Architect have given written approval to the specific deviation. The Contractor shall not be relieved of responsibility for errors or omissions in Shop Drawings, Product Data, Samples or similar submittals by the Construction Manager's and Architect's approval thereof. § 3.12.9 The Contractor shall direct specific attention, in writing or on resubmitted Shop Drawings, Product Data, Samples or similar submittals, to revisions other than those requested by the Construction Manager and Architect on previous submittals. § 3.12.10 Informational submittals upon which the Construction Manager and Architect are not expected to take responsive action may be so identified in the Contract Documents. § 3.12.11 When professional certification of performance criteria of materials, systems or equipment is required by the Contract Documents, the Construction Manager and Architect shall be entitled to rely upon the accuracy and completeness of such calculations and certifications. § 3.13 USE OF SITE § 3.13.1 The Contractor shall confine operations at the site to areas permitted by law, ordinances, permits and the Contract Documents and shall not unreasonably encumber the site with materials or equipment. § 3.13.2 The Contractor shall coordinate the Contractor's operations with, and secure the approval of, the Construction Manager before using any portion of the site. § 3.14 CUTTING AND PATCHING § 3.14.1 The Contractor shall be responsible for cutting, fitting or patching required to complete the Work or to make its parts fit together properly. § 3.14.2 The Contractor shall not damage or endanger a portion of the Work or fully or partially completed construction of the Owner's own forces or of other Contractors by cutting, patching, excavating or otherwise altering such construction. The Contractor shall not cut or otherwise alter such construction by other Contractors or by the Owner's own forces except with written consent of the Construction Manager, Owner and such other Contractors; such consent shall not be unreasonably withheld. The Contractor shall not unreasonably withhold from the other Contractors or the Owner the Contractor's consent to cutting or otherwise altering the Work. § 13.5 CLEANING UP § 13.5.1 The Contractor shall keep the premises and surrounding area free from accumulation of waste materials or rubbish caused by operations under the Contract. At completion of the Work the Contractor shall remove from and about the Project waste materials, rubbish, the Contractor's tools, construction equipment, machinery and surplus materials. § 3.15.2 If the Contractor fails to clean up as provided in the Contract Documents, the Construction Manager may do so with the Owner's approval and the cost thereof shall be charged to the Contractor. § 3.16 ACCESS TO WORK § 3.16.1 The Contractor shall provide the Owner, Construction Manager and Architect access to the Work in preparation and progress wherever located. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 23 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 3.17 ROYALTIES AND PATENTS § 3.17.1 The Contractor shall pay all royalties and license fees. The Contractor shall defend suits or claims for infringement of patent rights and shall hold the Owner, Construction Manager and Architect harmless from loss on account thereof, but shall not be responsible for such defense or loss when a particular design, process or product of a particular manufacturer or manufacturers is required by the Contract Documents. However, if the Contractor has reason to believe that the required design, process or product is an infringement of a patent, the Contractor shall be responsible for such loss unless such information is promptly furnished to the Architect. § 3.18 INDEMNIFICATION § 3.18.1 To the fullest extent permitted by law, the Contractor shall indemnify and hold harmless the Owner, Construction Manager, Architect, Construction Manager's and Architect's consultants, and agents and employees of any of them from and against claims, damages, losses and expenses, including but not limited to attorneys' fees, arising out of or resulting from performance of the Work, provided that such claim, damage, loss or expense is attributable to bodily injury, sickness, disease or death, or to injury to or destruction of tangible property (other than the Work itself) including loss of use resulting therefrom, but only to the extent caused in whole or in part by negligent acts or omissions of the Contractor, a Subcontractor, anyone directly or indirectly employed by them or anyone for whose acts they may be liable, regardless of whether or not such claim, damage, loss or expense is caused in part by a party indemnified hereunder. Such obligation shall not be construed to negate, abridge or reduce other rights or obligations of indemnity which would otherwise exist as to a party or person described in this Section 3.18. § 3.18.2 In claims against any person or entity indemnified under this Section 3.18 by an employee of the Contractor, a Subcontractor, anyone directly or indirectly employed by them or anyone for whose acts they may be liable, the indemnification obligation under this Section 3.18 shall not be limited by a limitation on amount or type of damages, compensation or benefits payable by or for the Contractor or a Subcontractor under workers' compensation acts, disability benefit acts or other employee benefit acts. § 3.18.3 The obligations of the Contractor under this Section 3.18 shall not extend to the liability of the Construction Manager, Architect, their consultants, and agents and employees of any of them arising out of (1) the preparation or approval of maps, drawings, opinions, reports, surveys, Change Orders, designs or specifications, or (2) the giving of or the failure to give directions or instructions by the Construction Manager, Architect, their consultants, and agents and employees of any of them provided such giving or failure to give is the primary cause of the injury or damage. ARTICLE 4 ADMINISTRATION OF THE CONTRACT § 4.1 ARCHITECT § 4.1.1 The Architect is the person lawfully licensed to practice architecture or an entity lawfully practicing architecture identified as such in the Agreement and is referred to throughout the Contract Documents as if singular in number. The term "Architect" means the Architect or the Architect's authorized representative. § 4.2 CONSTRUCTION MANAGER § 4.2.1 The Construction Manager is the person or entity identified as such in the Agreement and is referred to throughout the Contract Documents as if singular in number. The term "Construction Manager" means the Construction Manager or the Construction Manager's authorized representative. § 4.3 Duties, responsibilities and limitations of authority of the Construction Manager and Architect as set forth in the Contract Documents shall not be restricted, modified or extended without written consent of the Owner, Construction Manager, Architect and Contractor. Consent shall not be unreasonably withheld. § 4.4 In case of termination of employment of the Construction Manager or Architect, the Owner shall appoint a construction manager or architect against whom the Contractor makes no reasonable objection and whose status under the Contract Documents shall be that of the former construction manager or architect, respectively. § 4.5 . AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 24 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 4.6 ADMINISTRATION OF THE CONTRACT § 4.6.1 The Construction Manager and Architect will provide administration of the Contract as described in the Contract Documents, and will be the Owner's representatives (1) during construction, (2) until final payment is due and (3) with the Owner's concurrence, from time to time during the correction period described in Section 12.2. The Construction Manager and Architect will advise and consult with the Owner and will have authority to act on behalf of the Owner only to the extent provided in the Contract Documents, unless otherwise modified by written instrument in accordance with other provisions of the Contract. § 4.6.2 The Construction Manager will determine in general that the Work is being performed in accordance with the requirements of the Contract Documents, will keep the Owner informed of the progress of the Work, and will endeavor to guard the Owner against defects and deficiencies in the Work. § 4.6.3 The Construction Manager will provide for coordination of the activities of other Contractors and of the Owner's own forces with the Work of the Contractor, who shall cooperate with them. The Contractor shall participate with other Contractors and the Construction Manager and Owner in reviewing their construction schedules when directed to do so. The Contractor shall make any revisions to the construction schedule deemed necessary after a joint review and mutual agreement. The construction schedules shall constitute the schedules to be used by the Contractor, other Contractors, the Construction Manager and the Owner until subsequently revised. § 4.6.4 The Construction Manager will schedule and coordinate the activities of the Contractors in accordance with the latest approved Project construction schedule. § 4.6.5 The Architect will visit the site at intervals appropriate to the stage of construction to become generally familiar with the progress and quality of the completed Work and to determine in general if the Work is being performed in a manner indicating that the Work, when completed, will be in accordance with the Contract Documents. However, the Architect will not be required to make exhaustive or continuous on -site inspections to check quality or quantity of the W,,,a, O the b of on site o . tions Work, except as an fehiteet, th d f an d d ieieneies therwise provided in the � a � Contract Documents. On the basis of on -site observations as an architect, the Architect will keep the Owner informed of progress of the Work, and will endeavor to guard the Owner against defects and deficiencies in the Work. § 4.6.6 The Construction Manager, except to the extent required by Section 4.6.4, and Architect will not have control over or charge of and will not be responsible for construction means, methods, techniques, sequences or procedures, or for safety precautions and programs in connection with the Work, since these are solely the Contractor's responsibility as provided in Section 3.3, and neither will be responsible for the Contractor's failure to carry out the Work in accordance with the Contract Documents, except as otherwise provided in the Contract Documents. Neither the Construction Manager nor the Architect will have control over or charge of or be responsible for acts or omissions of the Contractor, Subcontractors, or their agents or employees, or of any other persons performing portions of the Work. § 4.6.7 Communications Facilitating Contract Administration. Except as otherwise provided in the Contract Documents or when direct communications have been specially authorized, the Owner and Contractor shall communicate through the Construction Manager, and shall contemporaneously provide the same communications to the Architect. Communications by and with the Architect's consultants shall be through the Architect. Communications by and with Subcontractors and material suppliers shall be through the Contractor. Communications by and with other Contractors shall be through the Construction Manager and shall be contemporaneously provided to the Architect. § 4.6.8 The Construction Manager will review and certify all Applications for Payment by the Contractor, including final payment. The Construction Manager will assemble each of the Contractor's Applications for Payment with similar Applications from other Contractors into a Project Application and Project Certificate for Payment. After reviewing and certifying the amounts due the Contractors, the Construction Manager will submit the Project Application and Project Certificate for Payment, along with the applicable Contractors' Applications and Certificates for Payment, to the Architect. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 25 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 4.6.9 Based on the Architect's observations and evaluations of Contractors' Applications for Payment, and the certifications of the Construction Manager, the Architect will review and certify the amounts due the Contractors and will issue a Project Certificate for Payment. § 4.6.10 The Architect will have authority to reject Work which does not conform to the Contract Documents, and to require additional inspection or testing, in accordance with Sections 13.5.2 and 13.5.3, whether or not such Work is fabricated, installed or completed, but will take such action only after notifying the Construction Manager. Subject to review by the Architect, the Construction Manager will have the authority to reject Work which does not conform to the Contract Documents. Whenever the Construction Manager considers it necessary or advisable for implementation of the intent of the Contract Documents, the Construction Manager will have authority to require additional inspection or testing of the Work in accordance with Sections 13.5.2 and 13.5.3, whether or not such Work is fabricated, installed or completed. The foregoing authority of the Construction Manager will be subject to the provisions of Sections 4.6.18 through 4.6.20 inclusive, with respect to interpretations and decisions of the Architect. However, neither the Architect's nor the Construction Manager's authority to act under this Section 4.6. 10 nor a decision made by either of them in good faith either to exercise or not to exercise such authority shall give rise to a duty or responsibility of the Architect or the Construction Manager to the Contractor, Subcontractors, material and equipment suppliers, their agents or employees, or other persons performing any of the Work. § 4.6.11 The Construction Manager will receive from the Contractor and review and approve all Shop Drawings, Product Data and Samples, coordinate them with information received from other Contractors, and transmit to the Architect those recommended for approval. The Construction Manager's actions will be taken with such reasonable promptness as to cause no delay in the Work of the Contractor or in the activities of other Contractors, the Owner, or the Architect. § 4.6.12 The Architect will review and approve or take other appropriate action upon the Contractor's submittals such as Shop Drawings, Product Data and Samples, but only for the limited purpose of checking for conformance with information given and the design concept expressed in the Contract Documents. The Architect's action will be taken with such reasonable promptness as to cause no delay in the Work of the Contractor or in the activities of the other Contractors, the Owner, or the Construction Manager, while allowing sufficient time in the Architect's professional judgment to permit adequate review. Review of such submittals is not conducted for the purpose of determining the accuracy and completeness of other details such as dimensions and quantities, or for substantiating instructions for installation or performance of equipment or systems, all of which remain the responsibility of the Contractor as required by the Contract Documents. The Architect's review of the Contractor's submittals shall not relieve the Contractor of the obligations under Sections 3.3, 3.5 and 3.12. The Architect's review shall not constitute approval of safety precautions or, unless otherwise specifically stated by the Architect, of any construction means, methods, techniques, sequences or procedures. The Architect's approval of a specific item shall not indicate approval of an assembly of which the item is a component. § 4.6.13 The Construction Manager will prepare Change Orders and Construction Change Directives. § 4.6.14 Following consultation with the Construction Manager, the Architect will take appropriate action on Change Orders or Construction Change Directives in accordance with Article 7 and will have authority to order minor changes in the Work as provided in Section 7.4. § 4.6.15 The Construction Manager will maintain at the site for the Owner one record copy of all Contracts, Drawings, Specifications, addenda, Change Orders and other Modifications, in good order and marked currently to record all changes and selections made during construction, and in addition approved Shop Drawings, Product Data, Samples and similar required submittals. These will be available to the Architect and the Contractor, and will be delivered to the Owner upon completion of the Project. § 4.6.16 The Construction Manager will assist the Architect in conducting inspections to determine the dates of Substantial Completion and final completion, and will receive and forward to the Architect written warranties and related documents required by the Contract and assembled by the Contractor. The Construction Manager will forward to the Architect a final Project Application and Project Certificate for Payment upon compliance with the requirements of the Contract Documents. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 26 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 4.6.17 If the Owner and Architect agree, the Architect will provide one or more project representatives to assist in carrying out the Architect's responsibilities at the site. The duties, responsibilities and limitations of authority of such project representatives shall be as set forth in an exhibit to be incorporated in the Contract Documents. § 4.6.18 The Architect will interpret and decide matters concerning performance under and requirements of the Contract Documents on written request of the Construction Manager, Owner or Contractor. The Architect's response to such requests will be made with reasonable promptness and within any time limits agreed upon. If no agreement is made concerning the time within which interpretations required of the Architect shall be furnished in compliance with this Section 4.6, then delay shall not be recognized on account of failure by the Architect to furnish such interpretations until 15 days after written request is made for them. § 4.6.19 Interpretations and decisions of the Architect will be consistent with the intent of and reasonably inferable from the Contract Documents and will be in writing or in the form of drawings. When making such interpretations and decisions, the Architect will endeavor to secure faithful performance by both Owner and Contractor, will not show partiality to either and will not be liable for results of interpretations or decisions so rendered in good faith. § 4.6.20 The Architect's decisions on matters relating to aesthetic effect will be final if consistent with the intent expressed in the Contract Documents. § 4.7 CLAIMS AND DISPUTES § 4.7.1 Definition. A Claim is a demand or assertion by one of the parties seeking, as a matter of right, adjustment or interpretation of Contract terms, payment of money, extension of time or other relief with respect to the terms of the Contract. The term "Claim" also includes matters in question between the Owner and Contractor arising out of or relating to the Contract. Claims must be made by written notice. The responsibility to substantiate Claims shall rest with the party making the Claim. § 4.7.2 Decision of Architect. Claims, including those alleging an error or omission by the Construction Manager or Architect, shall be referred initially to the Architect for action as provided in Section 4.8. A decision by the Architect, as provided in Section 4.8.4, shall be required as a condition precedent to arbitration of litigation f a Claim between the Contractor and Owner as to all such matters arising prior to the date final payment is due, regardless of (1) whether such matters relate to execution and progress of the Work or (2) the extent to which the Work has been completed. The decision by the Architect in response to a Claim shall not be a condition precedent to afb4atiafi or- litigation in the event (1) the position of Architect is vacant, (2) the Architect has not received evidence or has failed to render a decision within agreed time limits, (3) the Architect has failed to take action required under Section 4.8.4 within 30 days after the Claim is made, (4) 45 days have passed after the Claim has been referred to the Architect or (5) the Claim relates to a mechanic's lien. § 4.7.3 Time Limits on Claims. Claims by either party must be made within 21 days after occurrence of the event giving rise to such Claim or within 21 days after the claimant first recognizes the condition giving rise to the Claim, whichever is later. Claims must be made by written notice. An additional Claim made after the initial Claim has been implemented by Change Order will not be considered unless submitted in a timely manner. § 4.7.4 Continuing Contract Performance. Pending final resolution of a , Claim, unless otherwise agreed in writing the Contractor shall proceed diligently with performance of the Contract and the Owner shall continue to make payments in accordance with the Contract Documents. § 4.7.5 Waiver of Claims: Final Payment. The making of final payment shall constitute a waiver of Claims by the Owner except those arising from: .1 liens, Claims, security interests or encumbrances arising out of the Contract and unsettled; .2 failure of the Work to comply with the requirements of the Contract Documents; or .3 terms of special warranties required by the Contract Documents. § 4.7.6 Claims for Concealed or Unknown Conditions. If conditions are encountered at the site which are (1) subsurface or otherwise concealed physical conditions which differ materially from those indicated in the Contract Documents or (2) unknown physical conditions of an unusual nature, which differ materially from those ordinarily found to exist and generally recognized as inherent in construction activities of the character provided for in the Contract Documents, then notice by the observing party shall be given to the other party promptly before conditions AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 27 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) are disturbed and in no event later than 21 days after first observance of the conditions. The Architect will promptly investigate such conditions and, if they differ materially and cause an increase or decrease in the Contractor's cost of, or time required for, performance of any part of the Work, will recommend an equitable adjustment in the Contract Sum or Contract Time, or both. If the Architect determines that the conditions at the site are not materially different from those indicated in the Contract Documents and that no change in the terms of the Contract is justified, the Architect shall so notify the Owner and Contractor in writing, stating the reasons. Claims by either party in opposition to such determination must be made within 21 days after the Architect has given notice of the decision. If the Owner and Contractor cannot agree on an adjustment in the Contract Sum or Contract Time, the adjustment shall be referred to the Architect for initial determination, subject to further proceedings pursuant to Section 4.8. § 4.7.7 Claims for Additional Cost. If the Contractor wishes to make Claim for an increase in the Contract Sum, written notice as provided herein shall be given before proceeding to execute the Work. Prior notice is not required for Claims relating to an emergency endangering life or property arising under Section 10.3. If the Contractor believes additional cost is involved for reasons including but not limited to (1) a written interpretation from the Architect, (2) an order by the Owner to stop the Work where the Contractor was not at fault, (3) a written order for a minor change in the Work issued by the Architect, (4) failure of payment by the Owner, (5) termination of the Contract by the Owner, (6) Owner's suspension or (7) other reasonable grounds, Claim shall be filed in accordance with the procedure established herein. § 4.7.8 Claims for Additional Time. § 4.7.8.1 If the Contractor wishes to make Claim for an increase in the Contract Time, written notice as provided herein shall be given. The Contractor's Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay only one Claim is necessary. § 4.7.8.2 If adverse weather conditions are the basis for a Claim for additional time, such Claim shall be documented by data substantiating that weather conditions were abnormal for the period of time and could not have been reasonably anticipated, and that weather conditions had an adverse effect on the scheduled construction. § 4.7.9 Injury or Damage to Person or Property. If either party to the Contract suffers injury or damage to person or property because of an act or omission of the other party, of any of the other party's employees or agents, or of others for whose acts such party is legally liable, written notice of such injury or damage, whether or not insured, shall be given to the other party within a reasonable time not exceeding 21 days after first observance. The notice shall provide sufficient detail to enable the other party to investigate the matter. If a Claim for additional cost or time related to this Claim is to be asserted, it shall be filed as provided in Sections 4.7.7 or 4.7.8. 4.7.10 DELAYS -No payment or Compensation of any kind shall be made to the Contractor for damage because of hindrance or delay from any cause in the progress of the work, whether such hindrance or delays be avoidable or unavoidable or forseen or unforeseen. § 4.8 RESOLUTION OF CLAIMS AND DISPUTES § 4.8.1 The Architect will review Claims and take one or more of the following preliminary actions within ten days of receipt of a Claim: (1) request additional supporting data from the claimant, (2) submit a schedule to the parties indicating when the Architect expects to take action, (3) reject the Claim in whole or in part, stating reasons for rejection, (4) recommend approval of the Claim by the other party or (5) suggest a compromise. The Architect may also, but is not obligated to, notify the surety, if any, of the nature and amount of the Claim. § 4.8.2 If a Claim has been resolved, the Architect will prepare or obtain appropriate documentation. § 4.8.3 If a Claim has not been resolved, the party making the Claim shall, within ten days after the Architect's preliminary response, take one or more of the following actions: (1) submit additional supporting data requested by the Architect, (2) modify the initial Claim or (3) notify the Architect that the initial Claim stands. § 4.8.4 If a Claim has not been resolved after consideration of the foregoing and of further evidence presented by the parties or requested by the Architect, the Architect will notify the parties in writing that the Architect's decision will AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 28 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) be made within seven days, which decision shall be final. Upon expiration of such time period, the Architect will render to the parties the Architect's written decision relative to the Claim, including any change in the Contract Sum or Contract Time or both. If there is a surety and there appears to be a possibility of a Contractor's default, the Architect may, but is not obligated to, notify the surety and request the surety's assistance in resolving the controversy. § 4.9 ADQ ONMEDIATION § 4.9.1 Any Claim arising out of or related to the Contract, , xcept ^ ntr- ovefsies of Claims relating to aesthetic effect and except those waived under the terms of the Contract Documents, shall, after initial decision by the Architect or 30 days after submission of the claim to the has gi ven Architect, be subject to mediation at the request of either party. Owner and Contractor expressly agree that mediation shall be ., a Claim has been ��tiondition precedent to the initiation of any litigation arising out of such Claims or the initiation arbitration (if mutually agreed in Seetion 4.7 and fie Eleeisio has been r-°fider -ed writing by the parties). § 4.9.2 Rules and Notiee -s The parties shall endeavor to resolve their claims by mediation. Requests for ^r-b' r G',.:,f.,. b,..•..eet mediation shall be filing in writing with the O f aci G,.,..,.,., to f nat fesek - ~deft: Seetion 4. shall, if other party to ,. n an d e ,. S n ^ . n .' — ,the Contract. Mediation shall be deeidec- Conducted by ,. f bi t ,. at io n i., ..,.eofd, w° any mutually greed mediator or, if agreement cannot be reached, with the r°n T lndas�r� American Arbitration Rules orAssociation. If the mediation is conducted by the American Arbitration Assoeiation euffently in effeet, unless the pafties mutually agfee other-wise. Notiee of demand Association, requests for mediation shall be filed with the O wnef r °#r ° ° * °r °Ha with the American Arbitration Association and eepies shall be €i4eEkonducted in accordance with the Construction . Industry Mediation Rules of the American Arbitration Association currently in effect. § 4.9.3 The parties shall share the mediators fee equally and, if any filing fee is required with the American Arbitration Association, shall share filing fees equally . Mediation shall be held within the county where the Project is located, unless another location is mutually agreed upon by the parties. Agreements reached in mediation shall be reduced to writing, signed by the parties, and shall eamply with Seetion 4.7.4. pafties have pfesented evidenee to the Ar-ehiteet of have been given feasonable oppofainit) to do so, if the Afehiteet has not r-endefed a final wfitten deeision by that date, or- (3) any of the five events desefibed in Seetion 4.7.2. § 4.9.4.1 When a wr-ittefi Eleeisi an of the Afehiteet states that (1) the Eleeision is fifial but subjeet to ar-134ation and (2� b le Seetion 4.9.4.1 as applieable, and in other- eases within a Feasena -hip- time af4er- the Glaiffl-has, in nw, § 4.9.5 Imii+i4ation an Consolidation or- Joinder-. No arbitt:a of or- r-elatifig to the Gafitr-aet Paeaments the Ar-ehiteet, at: the b , a AIA Document A201 /CMaTM - 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 29 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) 11114-4441; thpvpRf then be enforceable as provided by the Laws of the State of Tcxas.G- 6;Rl..,.eliw n.....e.. ARTICLE 5 SUBCONTRACTORS § 5.1 DEFINITIONS § 5.1.1 A Subcontractor is a person or entity who has a direct contract with the Contractor to perform a portion of the Work at the site. The term "Subcontractor" is referred to throughout the Contract Documents as if singular in number and means a Subcontractor or an authorized representative of the Subcontractor. The term "Subcontractor" does not include other Contractors or subcontractors of other Contractors. § 5.1.2 A Sub - subcontractor is a person or entity who has a direct or indirect contract with a Subcontractor to perform a portion of the Work at the site. The term "Sub- subcontractor" is referred to throughout the Contract Documents as if singular in number and means a Sub - subcontractor or an authorized representative of the Sub - subcontractor. § 5.2 AWARD OF SUBCONTRACTS AND OTHER CONTRACTS FOR PORTIONS OF THE WORK § 5.2.1 Unless otherwise stated in the Contract Documents or the bidding requirements, the Contractor, as soon as practicable after award of the Contract, shall furnish in writing to the Construction Manager for review by the Owner, Construction Manager and Architect the names of persons or entities (including those who are to furnish materials or equipment fabricated to a special design) proposed for each principal portion of the Work. The Construction Manager will promptly reply to the Contractor in writing stating whether or not the Owner, Construction Manager or Architect, after due investigation, has reasonable objection to any such proposed person or entity. Failure of the Construction Manager to reply promptly shall constitute notice of no reasonable objection. § 5.2.2 The Contractor shall not contract with a proposed person or entity to whom the Owner, Construction Manager or Architect has made reasonable and timely objection. The Contractor shall not be required to contract with anyone to whom the Contractor has made reasonable objection. § 5.2.3 If the Owner, Construction Manager or Architect has reasonable objection to a person or entity proposed by the Contractor, the Contractor shall propose another to whom the Owner, Construction Manager or Architect has no reasonable objection. The Contract Sum shall be increased or decreased by the difference in cost occasioned by such change and an appropriate Change Order shall be issued. However, no increase in the Contract Sum shall be allowed for such change unless the Contractor has acted promptly and responsively in submitting names as required. § 5.2.4 The Contractor shall not change a Subcontractor, person or entity previously selected if the Owner, Construction Manager or Architect makes reasonable objection to such change. § 5.3 SUBCONTRACTUAL RELATIONS § 5.3.1 By appropriate agreement, written where legally required for validity, the Contractor shall require each Subcontractor, to the extent of the Work to be performed by the Subcontractor, to be bound to the Contractor by AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 30 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) terms of the Contract Documents, and to assume toward the Contractor all the obligations and responsibilities which the Contractor, by these Documents, assumes toward the Owner, Construction Manager and Architect. Each subcontract agreement shall preserve and protect the rights of the Owner, Construction Manager and Architect under the Contract Documents with respect to the Work to be performed by the Subcontractor so that subcontracting thereof will not prejudice such rights, and shall allow to the Subcontractor, unless specifically provided otherwise in the subcontract agreement, the benefit of all rights, remedies and redress against the Contractor that the Contractor, by the Contract Documents, has against the Owner. Where appropriate, the Contractor shall require each Subcontractor to enter into similar agreements with Sub - subcontractors. The Contractor shall make available to each proposed Subcontractor, prior to the execution of the subcontract agreement, copies of the Contract Documents to which the Subcontractor will be bound, and, upon written request of the Subcontractor, identify to the Subcontractor terms and conditions of the proposed subcontract agreement which may be at variance with the Contract Documents. Subcontractors shall similarly make copies of applicable portions of such documents available to their respective proposed Sub - subcontractors. § 5.4 CONTINGENT ASSIGNMENT OF SUBCONTRACTS § 5.4.1 Each subcontract agreement for a portion of the Work is assigned by the Contractor to the Owner provided that: .1 assignment is effective only after termination of the Contract by the Owner for cause pursuant to Section 14.2 and only for those subcontract agreements which the Owner accepts by notifying the Subcontractor in writing; and .2 assignment is subject to the prior rights of the surety, if any, obligated under bond relating to the Contract. § 5.4.2 If the Work has been suspended for more than 30 days, the Subcontractor's compensation shall be equitably adjusted. 5.5.1 Contractor shall promptly notify the Owner and Architect of any material defaults by any Subcontractor. Notwithstanding any provision contained in Article 5 to the contrary, it is hereby acknowledged and agreed that Owner has in no wayagreed, expressly or implicitly, nor will Owner agree, to allow any Subcontractor or other materialman or workman employed by Contractor the right to obtain a personal judgment or to create a lien against Owner for the amount due from the Contractor. ARTICLE 6 CONSTRUCTION BY OWNER OR BY OTHER CONTRACTORS § 6.1 OWNER'S RIGHT TO PERFORM CONSTRUCTION WITH OWN FORCES AND TO AWARD OTHER CONTRACTS § 6.1.1 The Owner reserves the right to perform construction or operations related to the Project with the Owner's own forces, which include persons or entities under separate contracts not administered by the Construction Manager. The Owner further reserves the right to award other contracts in connection with other portions of the Project or other construction or operations on the site under Conditions of the Contract identical or substantially similar to these including those portions related to insurance and waiver of subrogation. If the Contractor claims that delay or additional cost is involved because of such action by the Owner, the Contractor shall make such Claim as provided elsewhere in the Contract Documents. § 6.1.2 When the Owner performs construction or operations with the Owner's own forces including persons or entities under separate contracts not administered by the Construction Manager, the Owner shall provide for coordination of such forces with the Work of the Contractor, who shall cooperate with them. § 6.1.3 Unless otherwise provided in the Contract Documents, when the Owner performs construction or operations related to the Project with the Owner's own forces, the Owner shall be deemed to be subject to the same obligations and to have the same rights which apply to the Contractor under the Conditions of the Contract, including, without excluding others, those stated in this Article 6 and in Articles 3, 10, 11 and 12. § 6.2 MUTUAL RESPONSIBILITY § 6.2.1 The Contractor shall afford the Owner's own forces, Construction Manager and other Contractors reasonable opportunity for introduction and storage of their materials and equipment and performance of their activities, and shall connect and coordinate the Contractor's construction and operations with theirs as required by the Contract Documents. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 31 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 6.2.2 If part of the Contractor's Work depends for proper execution or results upon construction or operations by the Owner's own forces or other Contractors, the Contractor shall, prior to proceeding with that portion of the Work, promptly report to the Construction Manager and Architect apparent discrepancies or defects in such other construction that would render it unsuitable for such proper execution and results. Failure of the Contractor so to report shall constitute an acknowledgment that the Owner's own forces or other Contractors' completed or partially completed construction is fit and proper to receive the Contractor's Work, except as to defects not then reasonably discoverable. § 6.2.3 Costs caused by delays or by improperly timed activities or defective construction shall be borne by the party responsible therefor. § 6.2.4 The Contractor shall promptly remedy damage wrongfully caused by the Contractor to completed construction or partially completed construction or to property of the Owner or other Contractors as provided in Section 10.2.5. § 6.2.5 Claims and other disputes and matters in question between the Contractor and other Contractors shall be subject to the provisions of Section 4.7 provided the other Contractors have reciprocal obligations. § 6.2.6 The Owner and other Contractors shall have the same responsibilities for cutting and patching as are described for the Contractor in Section 3.14. § 6.3 OWNER'S RIGHT TO CLEAN UP § 6.3.1 If a dispute arises among the Contractor, other Contractors and the Owner as to the responsibility under their respective contracts for maintaining the premises and surrounding area free from waste materials and rubbish as described in Section 3.15, the Owner may clean up and allocate the cost among those responsible as the Construction Manager, in consultation with the Architect, determines to be just. ARTICLE 7 CHANGES IN THE WORK § 7.1 CHANGES § 7.1.1 Changes in the Work may be accomplished after execution of the Contract, and without invalidating the Contract, by Change Order, Construction Change Directive or order for a minor change in the Work, subject to the limitations stated in this Article 7 and elsewhere in the Contract Documents. § 7.1.2 A Change Order shall be based upon agreement among the Owner, Construction Manager, Architect and Contractor; a Construction Change Directive requires agreement by the Owner, Construction Manager and Architect and may or may not be agreed to by the Contractor; an order for a minor change in the Work may be issued by the Architect alone. § 7.1.3 Changes in the Work shall be performed under applicable provisions of the Contract Documents, and Contractor shall proceed promptly, unless otherwise provided in the Change Order, Construction Change Directive or order for a minor change in the Work. § 7.1.4 If unit prices are stated in the Contract Documents or subsequently agreed upon, and if quantities originally contemplated are so changed in a proposed Change Order or Construction Change Directive that application of such unit prices to quantities of Work proposed will cause substantial inequity to the Owner or Contractor, the applicable unit prices shall be equitably adjusted. § 7.2 CHANGE ORDERS § 7.2.1 A Change Order is a written instrument prepared by the Construction Manager and signed by the Owner, Construction Manager, Architect and Contractor, stating their agreement upon all of the following: .1 a change in the Work; .2 the amount of the adjustment in the Contract Sum, if any; and .3 the extent of the adjustment in the Contract Time, if any. § 7.2.2 Methods used in determining adjustments to the Contract Sum may include those listed in Section 7.3.3. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 32 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 7.3 CONSTRUCTION CHANGE DIRECTIVES § 7.3.1 A Construction Change Directive is a written order prepared by the Construction Manager and signed by the Owner, Construction Manager and Architect, directing a change in the Work and stating a proposed basis for adjustment, if any, in the Contract Sum or Contract Time, or both. The Owner may by Construction Change Directive, without invalidating the Contract, order changes in the Work within the general scope of the Contract consisting of additions, deletions or other revisions, the Contract Sum and Contract Time being adjusted accordingly. § 7.3.2 A Construction Change Directive shall be used in the absence of total agreement on the terms of a Change Order. § 7.3.3 If the Construction Change Directive provides for an adjustment to the Contract Sum, the adjustment shall be based on one of the following methods: .1 mutual acceptance of a lump sum properly itemized and supported by sufficient substantiating data to permit evaluation; .2 unit prices stated in the Contract Documents or subsequently agreed upon; .3 cost to be determined in a manner agreed upon by the parties and a mutually acceptable fixed or percentage fee; or .4 as provided in Section 7.3.6. § 7.3.4 Upon receipt of a Construction Change Directive, the Contractor shall promptly proceed with the change in the Work involved and advise the Construction Manager and Architect of the Contractor's agreement or disagreement with the method, if any, provided in the Construction Change Directive for determining the proposed adjustment in the Contract Sum or Contract Time. § 7.3.5 A Construction Change Directive signed by the Contractor indicates the agreement of the Contractor therewith, including adjustment in Contract Sum and Contract Time or the method for determining them. Such agreement shall be effective immediately and shall be recorded as a Change Order. § 7.3.6 If the Contractor does not respond promptly or disagrees with the method for adjustment in the Contract Sum, the method and the adjustment shall be determined by the Construction Manager on the basis of reasonable expenditures and savings of those performing the Work attributable to the change, including, in case of an increase in the Contract Sum, a reasonable allowance for overhead and profit. In such case, and also under Section 7.3.3.3, the Contractor shall keep and present, in such form as the Construction Manager may prescribe, an itemized accounting together with appropriate supporting data. Unless otherwise provided in the Contract Documents, costs for the purposes of this Section 7.3.6 shall be limited to the following: .1 costs of labor, including social security, old age and unemployment insurance, fringe benefits required by agreement or custom, and workers compensation insurance; .2 costs of materials, supplies and equipment, including cost of transportation, whether incorporated or consumed; .3 rental costs of machinery and equipment, exclusive of hand tools, whether rented from the Contractor or others; .4 costs of premiums for all bonds and insurance, permit fees, and sales, use or similar taxes related to the Work; and .5 additional costs of supervision and field office personnel directly attributable to the change. § 7.3.7 Pending final determination of cost to the Owner, amounts not in dispute may be included in Applications for Payment. The amount of credit to be allowed by the Contractor to the Owner for a deletion or change which results in a net decrease in the Contract Sum shall be actual net cost as confirmed by the Construction Manager. When both additions and credits covering related Work or substitutions are involved in a change, the allowance for overhead and profit shall be figured on the basis of net increase, if any, with respect to that change. § 7.3.8 If the Owner and Contractor do not agree with the adjustment in Contract Time or the method for determining it, the adjustment or the method shall be referred to the Construction Manager for determination. § 7.3.9 When the Owner and Contractor agree with the determination made by the Construction Manager concerning the adjustments in the Contract Sum and Contract Time, or otherwise reach agreement upon the adjustments, such AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 33 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) agreement shall be effective immediately issued through the Construction Manager and shall be recorded by preparation and execution of an appropriate Change Order. § 7.4 MINOR CHANGES IN THE WORK § 7.4.1 The Architect will have authority to order minor changes in the Work not involving adjustment in the Contract Sum or extension of the Contract Time and not inconsistent with the intent of the Contract Documents. Such changes shall be effected by written order issued through the Construction Manager and shall be binding on the Owner and Contractor. The Contractor shall carry out such written orders promptly. ARTICLE 8 TIME § 8.1 DEFINITIONS § 8.1.1 Unless otherwise provided, Contract Time is the period of time, including authorized adjustments, allotted in the Contract Documents for Substantial Completion of the Work. § 8.1.2 The date of commencement of the Work is the date established in the Agreement. The date shall not be postponed by the failure to act of the Contractor or of persons or entities for whom the Contractor is responsible. § 8.1.3 The date of Substantial Completion is the date certified by the Architect in accordance with Section 9.8. § 8.1.4 The term "day" as used in the Contract Documents shall mean calendar day unless otherwise specifically defined. § 8.2 PROGRESS AND COMPLETION § 8.2.1 Time limits stated in the Contract Documents are of the essence of the Contract. By executing the Agreement the Contractor confirms that the Contract Time is a reasonable period for performing the Work. § 8.2.2 The Contractor shall not knowingly, except by agreement or instruction of the Owner in writing, prematurely commence operations on the site or elsewhere prior to the effective date of insurance required by Article 11 to be furnished by the Contractor. The date of commencement of the Work shall not be changed by the effective date of such insurance. Unless the date of commencement is established by a notice to proceed given by the Owner, the Contractor shall notify the Owner in writing not less than five days or other agreed period before commencing the Work to permit the timely filing of mortgages, mechanic's liens and other security interests. § 8.2.3 The Contractor shall proceed expeditiously with adequate forces and shall achieve Substantial Completion within the Contract Time. § 8.3 DELAYS AND EXTENSIONS OF TIME § 8.3.1 If the Contractor is delayed at any time in progress of the Work by an act or neglect of the Owner's own forces, Construction Manager, Architect, any of the other Contractors or an employee of any of them, or by changes ordered in the Work, or by labor disputes, fire, unusual delay in deliveries, unavoidable casualties or other causes beyond the Contractor's control, or by delay authorized by the Owner pending arbitration, or by other causes which the Architect, based on the recommendation of the Construction Manager, determines may justify delay, then the Contract Time shall be extended by Change Order for such reasonable time as the Architect may determine. § 8.3.2 Claims relating to time shall be made in accordance with applicable provisions of Section 4.7. § 8.3.3 This Section 8.3 does not preclude recovery of damages for delay by either party under other provisions of the Contract Documents. ARTICLE 9 PAYMENTS AND COMPLETION § 9.1 CONTRACT SUM § 9.1.1 The Contract Sum is stated in the Agreement and, including authorized adjustments, is the total amount payable by the Owner to the Contractor for performance of the Work under the Contract Documents. § 9.2 SCHEDULE OF VALUES § 9.2.1 Before the first Application for Payment, the Contractor shall submit to the Architect, through the Construction Manager, a schedule of values allocated to various portions of the Work, prepared in such form and AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 34 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) supported by such data to substantiate its accuracy as the Construction Manager and Architect may require. This schedule, unless objected to by the Construction Manager or Architect, shall be used as a basis for reviewing the Contractor's Applications for Payment. § 9.3 APPLICATIONS FOR PAYMENT § 9.3.1 At least fifteen days before the date established for each progress payment, the Contractor shall submit to the Construction Manager an itemized Application for Payment for Work completed in accordance with the schedule of values. Such application shall be notarized, if required, and supported by such data substantiating the Contractor's right to payment as the Owner, Construction Manager or Architect may require, such as copies of requisitions from Subcontractors and material suppliers, and reflecting retainage if provided for elsewhere in the Contract Documents. § 9.3.1.1 Such applications may include requests for payment on account of changes in the Work which have been properly authorized by Construction Change Directives but not yet included in Change Orders. § 9.3.1.2 Such applications may not include requests for payment of amounts the Contractor does not intend to pay to a Subcontractor or material supplier because of a dispute or other reason. § 9.3.2 Unless otherwise provided in the Contract Documents, payments shall be made on account of materials and equipment delivered and suitably stored at the site for subsequent incorporation in the Work. If approved in advance by the Owner, payment may similarly be made for materials and equipment suitably stored off the site at a location agreed upon in writing. Payment for materials and equipment stored on or off the site shall be conditioned upon compliance by the Contractor with procedures satisfactory to the Owner to establish the Owner's title to such materials and equipment or otherwise protect the Owner's interest, and shall include applicable insurance, storage and transportation to the site for such materials and equipment stored off the site. § 9.3.3 The Contractor warrants that title to all Work covered by an Application for Payment will pass to the Owner no later than the time of payment. The Contractor further warrants that upon submittal of an Application for Payment all Work for which Certificates for Payment have been previously issued and payments received from the Owner shall, to the best of the Contractor's knowledge, information and belief, be free and clear of liens, claims, security interests or encumbrances in favor of the Contractor, Subcontractors, material suppliers, or other persons or entities making a claim by reason of having provided labor, materials and equipment relating to the Work. § 9.4 CERTIFICATES FOR PAYMENT § 9.4.1 The Construction Manager will assemble a Project Application for Payment by combining the Contractor's applications with similar applications for progress payments from other Contractors and, after certifying the amounts due on such applications, forward them to the Architect within seven days. § 9.4.2 Within seven days after the Architect's receipt of the Project Application for Payment, the Construction Manager and Architect will either issue to the Owner a Project Certificate for Payment, with a copy to the Contractor, for such amount as the Construction Manager and Architect determine is properly due, or notify the Contractor and Owner in writing of the Construction Manager's and Architect's reasons for withholding certification in whole or in part as provided in Section 9.5.1. Such notification will be forwarded to the Contractor by the Construction Manager. § 9.4.3 The issuance of a separate Certificate for Payment or a Project Certificate for Payment will constitute representations made separately by the Construction Manager and Architect to the Owner, based on their individual observations at the site and the data comprising the Application for Payment submitted by the Contractor, that the Work has progressed to the point indicated and that, to the best of the Construction Manager's and Architect's knowledge, information and belief, quality of the Work is in accordance with the Contract Documents. The foregoing representations are subject to an evaluation of the Work for conformance with the Contract Documents upon Substantial Completion, to results of subsequent tests and inspections, to minor deviations from the Contract Documents correctable prior to completion and to specific qualifications expressed by the Construction Manager or Architect. The issuance of a separate Certificate for Payment or a Project Certificate for Payment will further constitute a representation that the Contractor is entitled to payment in the amount certified. However, the issuance of a separate Certificate for Payment or a Project Certificate for Payment will not be a representation that the Construction Manager or Architect has (1) made exhaustive or continuous on -site inspections to check the quality or quantity of the Work, (2) reviewed the Contractor's construction means, methods, techniques, sequences or AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 35 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) procedures, (3) reviewed copies of requisitions received from Subcontractors and material suppliers and other data requested by the Owner to substantiate the Contractor's right to payment or (4) made examination to ascertain how or for what purpose the Contractor has used money previously paid on account of the Contract Sum. § 9.5 DECISIONS TO WITHHOLD CERTIFICATION § 9.5.1 The Construction Manager or Architect may decide not to certify payment and may withhold a Certificate for Payment in whole or in part, to the extent reasonably necessary to protect the Owner, if in the Construction Manager's or Architect's opinion the representations to the Owner required by Section 9.4.3 cannot be made. If the Construction Manager or Architect is unable to certify payment in the amount of the Application, the Construction Manager or Architect will notify the Contractor and Owner as provided in Section 9.4.2. If the Contractor, Construction Manager and Architect cannot agree on a revised amount, the Construction Manager and Architect will promptly issue a Certificate for Payment for the amount for which the Construction Manager and Architect are able to make such representations to the Owner. The Construction Manager or Architect may also decide not to certify payment or, because of subsequently discovered evidence or subsequent observations, may nullify the whole or a part of a Certificate for Payment previously issued, to such extent as may be necessary in the Construction Manager's or Architect's opinion to protect the Owner from loss because of: .1 defective Work not remedied; .2 third party claims filed or reasonable evidence indicating probable filing of such claims; .3 failure of the Contractor to make payments properly to Subcontractors or for labor, materials or equipment; .4 reasonable evidence that the Work cannot be completed for the unpaid balance of the Contract Sum; .5 damage to the Owner or another contractor; .6 reasonable evidence that the Work will not be completed within the Contract Time, and that the unpaid balance would not be adequate to cover actual or liquidated damages for the anticipated delay; or .7 persistent failure to carry out the Work in accordance with the Contract Documents. § 9.5.2 When the above reasons for withholding certification are removed, certification will be made for amounts previously withheld. 9.5.3 Notwithstanding any _provision contained within this Article, if the work has not attained Substantial Completion within the contract time , subject to extensions of time allowed under these Conditions, Architect may withhold any further payment to Contractor to the extent necessary to preserve sufficient funds to complete the construction of the Project and to cover liquidated damages assessed against Contractor up to the time of Application for Payment and to the time it is reasonabl ay nticipated that Substantial Completion will be achieved. § 9.6 PROGRESS PAYMENTS § 9.6.1 After the Construction Manager and Architect have issued a Project Certificate for Payment, the Owner shall make payment in the manner and within the time provided in the Contract Documents, and shall so notify the Construction Manager and Architect. § 9.6.2 The Contractor shall promptly pay each Subcontractor, upon receipt of payment from the Owner, out of the amount paid to the Contractor on account of such Subcontractor's portion of the Work, the amount to which said Subcontractor is entitled, reflecting percentages actually retained from payments to the Contractor on account of such Subcontractor's portion of the Work. The Contractor shall, by appropriate agreement with each Subcontractor, require each Subcontractor to make payments to Sub - subcontractors in similar manner. § 9.6.3 The Construction Manager will, on request, furnish to a Subcontractor, if practicable, information regarding percentages of completion or amounts applied for by the Contractor and action taken thereon by the Owner, Construction Manager and Architect on account of portions of the Work done by such Subcontractor. § 9.6.4 Neither the Owner, Construction Manager nor Architect shall have an obligation to pay or to see to the payment of money to a Subcontractor except as may otherwise be required by law. § 9.6.5 Payment to material suppliers shall be treated in a manner similar to that provided in Sections 9.6.2, 9.6.3 and 9.6.4. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 36 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 9.6.6 A Certificate for Payment, a progress payment, or partial or entire use or occupancy of the Project by the Owner shall not constitute acceptance of Work not in accordance with the Contract Documents. § 9.7 FAILURE OF PAYMENT § 9.7.1 If, through no fault of the Contractor, 1) the Construction Manager and Architect do not issue a Project Certificate for Payment within fourteen days after the Construction Manager's receipt of the Contractor's Application for Payment or 2) the Owner does not pay the Contractor within seven days after the date established in the Contract Documents the amount certified by the Construction Manager and , Architect, then the Contractor may, upon seven additional days' written notice to the Owner, Construction Manager and Architect, stop the Work until payment of the amount owing has been received. The Contract Time shall be extended appropriately and the Contract Sum shall be increased by the amount of the Contractor's reasonable costs of shut -down, delay and start -up, which shall be accomplished as provided in Article 7. § 9.8 SUBSTANTIAL COMPLETION § 9.8.1 Substantial Completion is the stage in the progress of the Work when the Work or designated portion thereof is sufficiently complete in accordance with the Contract Documents so the Owner can occupy or utilize the Work for its intended use. § 9.8.2 When the Contractor considers that the Work, or a portion thereof which the Owner agrees to accept separately, is substantially complete, the Contractor and Construction Manager shall jointly prepare and submit to the Architect a comprehensive list of items to be completed or corrected. The Contractor shall proceed promptly to complete and correct items on the list. Failure to include an item on such list does not alter the responsibility of the Contractor to complete all Work in accordance with the Contract Documents. Upon receipt of the list, the Architect, assisted by the Construction Manager, will make an inspection to determine whether the Work or designated portion thereof is substantially complete. If the Architect's inspection discloses any item, whether or not included on the list, which is not in accordance with the requirements of the Contract Documents, the Contractor shall, before issuance of the Certificate of Substantial Completion, complete or correct such item upon notification by the Architect. The Contractor shall then submit a request for another inspection by the Architect, assisted by the Construction Manager, to determine Substantial Completion. When the Work or designated portion thereof is substantially complete, the Architect will prepare a Certificate of Substantial Completion which shall establish the date of Substantial Completion, shall establish responsibilities of the Owner and Contractor for security, maintenance, heat, utilities, damage to the Work and insurance, and shall fix the time within which the Contractor shall finish all items on the list accompanying the Certificate. Warranties required by the Contract Documents shall commence on the date of Substantial Completion of the Work or designated portion thereof unless otherwise provided in the Certificate of Substantial Completion. The Certificate of Substantial Completion shall be submitted to the Owner and Contractor for their written acceptance of responsibilities assigned to them in such Certificate. § 9.8.3 Upon Substantial Completion of the Work or designated portion thereof and upon application by the Contractor and certification by the Construction Manager and Architect, the Owner shall make payment, reflecting adjustment in retainage, if any, for such Work or portion thereof as provided in the Contract Documents. § 9.9 PARTIAL OCCUPANCY OR USE § 9.9.1 The Owner may occupy or use any completed or partially completed portion of the Work at any stage when such portion is designated by separate agreement with the Contractor, provided such occupancy or use is consented to by the insurer as required under Section 11.3.11 and authorized by public authorities having jurisdiction over the Work. Such partial occupancy or use may commence whether or not the portion is substantially complete, provided the Owner and Contractor have accepted in writing the responsibilities assigned to each of them for payments, retainage if any, security, maintenance, heat, utilities, damage to the Work and insurance, and have agreed in writing concerning the period for correction of the Work and commencement of warranties required by the Contract Documents. When the Contractor considers a portion substantially complete, the Contractor and Construction Manager shall jointly prepare and submit a list to the Architect as provided under Section 9.8.2. Consent of the Contractor to partial occupancy or use shall not be unreasonably withheld. The stage of the progress of the Work shall be determined by written agreement between the Owner and Contractor or, if no agreement is reached, by decision of the Architect after consultation with the Construction Manager. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 37 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 9.9.2 Immediately prior to such partial occupancy or use, the Owner, Construction Manager, Contractor and Architect shall jointly inspect the area to be occupied or portion of the Work to be used in order to determine and record the condition of the Work. § 9.9.3 Unless otherwise agreed upon, partial occupancy or use of a portion or portions of the Work shall not constitute acceptance of Work not complying with the requirements of the Contract Documents. § 9.10 FINAL COMPLETION AND FINAL PAYMENT § 9.10.1 Upon completion of the Work, the Contractor shall forward to the Construction Manager a written notice that the Work is ready for final inspection and acceptance and shall also forward to the Construction Manager a final Contractor's Application for Payment. Upon receipt, the Construction Manager will forward the notice and Application to the Architect who will promptly make such inspection. When the Architect, based on the recommendation of the Construction Manager, finds the Work acceptable under the Contract Documents and the Contract fully performed, the Construction Manager and Architect will promptly issue a final Certificate for Payment stating that to the best of their knowledge, information and belief, and on the basis of their observations and inspections, the Work has been completed in accordance with terms and conditions of the Contract Documents and that the entire balance found to be due the Contractor and noted in said final Certificate is due and payable. The Construction Manager's and Architect's final Certificate for Payment will constitute a further representation that conditions listed in Section 9.10.2 as precedent to the Contractor's being entitled to final payment have been fulfilled. § 9.10.2 Neither final payment nor any remaining retained percentage shall become due until the Contractor submits to the Architect through the Construction Manager (1) an affidavit that payrolls, bills for materials and equipment, and other indebtedness connected with the Work for which the Owner or the Owner's property might be responsible or encumbered (less amounts withheld by Owner) have been paid or other wise satisfied, (2) a certificate evidencing that insurance required by the Contract Documents to remain in force after final payment is currently in effect and will not be canceled or allowed to expire until at least 30 days' prior written notice has been given to the Owner, (3) a written statement that the Contractor knows of no substantial reason that the insurance will not be renewable to cover the period required by the Contract Documents, (4) consent of surety, if any, to final payment and (5), if required by the Owner, other data establishing payment or satisfaction of obligations, such as receipts, releases and waivers of liens, claims, security interests or encumbrances arising out of the Contract, to the extent and in such form as may be designated by the Owner. If a Subcontractor refuses to furnish a release or waiver required by the Owner, the Contractor may furnish a bond satisfactory to the Owner to indemnify the Owner against such lien. If such lien remains unsatisfied after payments are made, the Contractor shall refund to the Owner all money that the Owner may be compelled to pay in discharging such lien, including all costs and reasonable attorneys' fees. § 9.10.3 If, after Substantial Completion of the Work, final completion thereof is materially delayed through no fault of the Contractor or by issuance of Change Orders affecting final completion, and the Construction Manager and Architect so confirm, the Owner shall, upon application by the Contractor and certification by the Construction Manager and Architect, and without terminating the Contract, make payment of the balance due for that portion of the Work fully completed and accepted. If the remaining balance for Work not fully completed or corrected is less than retainage stipulated in the Contract Documents, and if bonds have been furnished, the written consent of surety to payment of the balance due for that portion of the Work fully completed and accepted shall be submitted by the Contractor to the Architect through the Construction Manager prior to certification of such payment. Such payment shall be made under terms and conditions governing final payment, except that it shall not constitute a waiver of Claims. The making of final payment shall constitute a waiver of Claims by the Owner as provided in Section 4.4.5. § 9.10.4 Acceptance of final payment by the Contractor, a Subcontractor or material supplier shall constitute a waiver of claims by that payee except those previously made in writing and identified by that payee as unsettled at the time of final Application for Payment. Such waivers shall be in addition to the waiver described in Section 4.7.5. ARTICLE 10 PROTECTION OF PERSONS AND PROPERTY § 10.1 SAFETY PRECAUTIONS AND PROGRAMS § 10.1.1 The Contractor shall be responsible for initiating, maintaining and supervising all safety precautions and programs in connection with the performance of the Contract. The Contractor shall submit the Contractor's safety program to the Construction Manager for review and coordination with the safety programs of other Contractors. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 3$ may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 10.1.2 In the event the Contractor encounters on the site material reasonably believed to be asbestos or polychlorinated biphenyl (PCB) which has not been rendered harmless, the Contractor shall immediately stop Work in the area affected and report the condition to the Owner, Construction Manager and Architect in writing. The Work in the affected area shall not thereafter be resumed except by written agreement of the Owner and Contractor if in fact the material is asbestos or polychlorinated biphenyl (PCB) and has not been rendered harmless. The Work in the affected area shall be resumed in the absence of asbestos or polychlorinated biphenyl (PCB), or when it has been rendered harmless, by written agreement of the Owner and Contractor, or in accordance with final determination by the Architect on which arbitration has not been demanded, or by arbitration under Article 4. § 10.1.3 The Contractor shall not be required pursuant to Article 7 to perform without consent any Work relating to asbestos or polychlorinated biphenyl (PCB). HNM,MV1�SST.�3lfI . NO, - : - M - =Tt. 11R1711�i. Ei�!ll R��t !!lL7lleRff.T.ffiSL'ISG�.f0=1 ... - afnissiefts of the Owner-, at4yafte Elit-eetly or- indir-eetly emplayed by the Owner- at- anyene 4;9r- whose aets the Owner- indemnified hefeundef. SHeh obligation shall not be eonstfued to flegate, abfidge of feduee other- fights a obligations of indemnity whieh woeld othe. -iis- exist — to a pafty of pefson desefibed in this Seetion 10. 1.4. § 10.1.5 If reasonable precautions will be inadequate to prevent foreseeable bodily injury or death to persons resulting from a material or substance encountered on the site by the Contractor, the Contractor shall, upon recognizing the condition, immediately stop Work in the affected area and report the condition to the Owner, Construction Manager and Architect in writing. The Owner, Contractor, Construction Manager and Architect shall then proceed in the same manner described in Section 10.1.2. § 10.1.6 The Owner shall be responsible for obtaining the services of a licensed laboratory to verify a presence or absence of the material or substance reported by the Contractor and, in the event such material or substance is found to be present, to verify that it has been rendered harmless. Unless otherwise required by the Contract Documents, the Owner shall furnish in writing to the Contractor, Construction Manager and Architect the names and qualifications of persons or entities who are to perform tests verifying the presence or absence of such material or substance or who are to perform the task of removal or safe containment of such material or substance. The Contractor, the Construction Manager and the Architect will promptly reply to the Owner in writing stating whether or not any of them has reasonable objection to the persons or entities proposed by the Owner. If the Contractor, Construction Manager or Architect has an objection to a person or entity proposed by the Owner, the Owner shall propose another to whom the Contractor, the Construction Manager and the Architect have no reasonable objection. § 10.2 SAFETY OF PERSONS AND PROPERTY § 10.2.1 The Contractor shall take reasonable precautions for safety of, and shall provide reasonable protection to prcvcnt damage, injury or loss to: .1 employees on the Work and other persons who may be affected thereby; .2 the Work and materials and equipment to be incorporated therein, whether in storage on or off the site, under care, custody or control of the Contractor or the Contractor's Subcontractors or Sub - subcontractors; .3 other property at the site or adjacent thereto, such as trees, shrubs, lawns, walks, pavements, roadways, structures and utilities not designated for removal, relocation or replacement in the course of construction; and .4 construction or operations by the Owner or other Contractors. § 10.2.2 The Contractor shall give notices and comply with applicable laws, ordinances, rules, regulations and lawful orders of public authorities bearing on safety of persons or property or their protection from damage, injury or loss. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 39 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 10.2.3 The Contractor shall erect and maintain, as required by existing conditions and performance of the Contract, reasonable safeguards for safety and protection, including posting danger signs and other warnings against hazards, promulgating safety regulations and notifying owners and users of adjacent sites and utilities. § 10.2.4 When use for storage of explosives or other hazardous materials or equipment or unusual methods are necessary for execution of the Work, the Contractor shall exercise utmost care and carry on such activities under supervision of properly qualified personnel. § 10.2.5 The Contractor shall promptly remedy damage and loss (other than damage or loss insured under property insurance required by the Contract Documents) to property referred to in Sections 10.2.1.2, 10.2.1.3 and 10.2.1.4 caused in whole or in part by the Contractor, a Subcontractor, a Sub - subcontractor, or anyone directly or indirectly employed by any of them, or by anyone for whose acts they may be liable and for which the Contractor is responsible under Sections 10.2.1.2, 10.2.1.3 and 10.2.1.4, except damage or loss attributable to acts or omissions of the Owner, Construction Manager or Architect or anyone directly or indirectly employed by any of them, or by anyone for whose acts any of them may be liable, and not attributable to the fault or negligence of the Contractor. The foregoing obligations of the Contractor are in addition to the Contractor's obligations under Section 3.18. § 10.2.6 The Contractor shall designate a responsible member of the Contractor's organization at the site whose duty shall be the prevention of accidents. This person shall be the Contractor's superintendent unless otherwise designated by the Contractor in writing to the Owner, Construction Manager and Architect. § 10.2.7 The Contractor shall not load or permit any part of the construction or site to be loaded so as to endanger its safety. § 10.3 EMERGENCIES § 10.3.1 In an emergency affecting safety or persons or property, the Contractor shall act, at the Contractor's discretion, to prevent threatened damage, injury or loss. Additional compensation or extension of time claimed by the Contractor on account of an emergency shall be determined as provided in Section 4.7 and Article 7. ARTICLE 11 INSURANCE AND BONDS § 11.1 CONTRACTOR'S LIABILITY INSURANCE § 11. 1.1 The Contractor shall purchase from and maintain in a company or companies lawfully authorized to do business in the jurisdiction in which the Project is located such insurance as will protect the Contractor from claims set forth below which may arise out of or result from the Contractor's operations under the Contract and for which the Contractor may be legally liable, whether such operations be by the Contractor or by a Subcontractor or by anyone directly or indirectly employed by any of them, or by anyone for whose acts any of them may be liable: .1 claims under workers compensation, disability benefit and other similar employee benefit acts which are applicable to the Work to be performed; .2 claims for damages because of bodily injury, occupational sickness or disease, or death of the Contractor's employees; .3 claims for damages because of bodily injury, sickness or disease, or death of any person other than the Contractor's employees; .4 claims for damages insured by usual personal injury liability coverage which are sustained (1) by a person as a result of an offense directly or indirectly related to employment of such person by the Contractor, or (2) by another person; .5 claims for damages, other than to the Work itself, because of injury to or destruction of tangible property, including loss of use resulting therefrom; .6 claims for damages because of bodily injury, death of a person or property damage arising out of ownership, maintenance or use of a motor vehicle; and .7 claims involving contractual liability insurance applicable to the Contractor's obligations under Section 3.18. § 11.1.2 The insurance required by Section 11. 1.1 shall be written for not less than limits of liability specified in the Contract Documents or required by law, whichever coverage is greater. Coverages, whether written on an occurrence or claims -made basis, shall be maintained without interruption from date of commencement of the Work until date of final payment and termination of any coverage required to be maintained after final payment. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 40 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 11.1.3 Certificates of insurance acceptable to the Owner shall be submitted to the Construction Manager for transmittal to the Owner with a copy to the Architect prior to commencement of the Work. These certificates and the insurance policies required by this Section 11.1 shall contain a provision that coverages afforded under the policies will not be canceled or allowed to expire until at least 30 days' prior written notice has been given to the Owner. If any of the foregoing insurance coverages are required to remain in force after final payment and are reasonably available, an additional certificate evidencing continuation of such coverage shall be submitted with the final Application for Payment as required by Section 9.10.2. Information concerning reduction of coverage shall be furnished by the Contractor with reasonable promptness in accordance with the Contractor's information and belief. 4 11.1.4 Any failure of Contractor to comply with the reporting provisions of the policies shall not affect the coverage provided to the Owner. its officers. emplovees or volunteers. 4 11.1.5 All workers on the project site must be covered by the required insurance policies of the General Contractor or a Subcontractor. 4 11.1.6 All policies or certificates shall name the Owner as an additional insured on all applicable coverage. § 11.2 OWNER'S LIABILITY INSURANCE § 11.2.1 The Owner shall be responsible for purchasing and maintaining the Owner's usual liability insurance. Optionally, the Owner may purchase and maintain other insurance for self - protection against claims which may arise from operations under the Contract. The Contractor shall not be responsible for purchasing and maintaining this optional Owner's liability insurance unless specifically required by the Contract Documents. § 11.3 PROPERTY INSURANCE § 11.3.1 Unless otherwise provided, the Owner shall purchase and maintain, in a company or companies lawfully authorized to do business in the jurisdiction in which the Project is located, property insurance in the amount of the initial Contract Sum as well as subsequent modifications thereto for the entire Work at the site on a replacement cost basis without voluntary deductibles. Such property insurance shall be maintained, unless otherwise provided in the Contract Documents or otherwise agreed in writing by all persons and entities who are beneficiaries of such insurance, until final payment has been made as provided in Section 9.10 or until no person or entity other than the Owner has an insurable interest in the property required by this Section 11.3 to be covered, whichever is earlier. This insurance shall include interests of the Owner, the Contractor, Subcontractors and Sub - subcontractors in the Work. § 11.3.1.1 Property insurance shall be on an "all- risk" policy form and shall insure against the perils of fire and extended coverage and physical loss or damage including, without duplication of coverage, theft, vandalism, malicious mischief, collapse, falsework, temporary buildings and debris removal including demolition occasioned by enforcement of any applicable legal requirements, and shall cover reasonable compensation for Architect's services and expenses required as a result of such insured loss. Coverage for other perils shall not be required unless otherwise provided in the Contract Documents. § 11.3.1.2 If the Owner does not intend to purchase such property insurance required by the Contract and with all of the coverages in the amount described above, the Owner shall so inform the Contractor in writing prior to commencement of the Work. The Contractor may then effect insurance which will protect the interests of the Contractor, Subcontractors and Sub - subcontractors in the Work, and by appropriate Change Order the cost thereof shall be charged to the Owner. If the Contractor is damaged by the failure or neglect of the Owner to purchase or maintain insurance as described above, without so notifying the Contractor, then the Owner shall bear all reasonable costs properly attributable thereto. § 11.3.1.3 If the property insurance requires minimum deductibles and such deductibles are identified in the Contract Documents, the Contractor shall pay costs not covered because of such deductibles. If the Owner or insurer increases the required minimum deductibles above the amounts so identified or if the Owner elects to purchase this insurance with voluntary deductible amounts, the Owner shall be responsible for payment of the additional costs not covered because of such increased or voluntary deductibles. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 41 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 11.3.1.4 Unless otherwise provided in the Contract Documents, this property insurance shall cover portions of the Work stored off the site after written approval of the Owner at the value established in the approval, and also portions of the Work in transit. § 11.3.1.5 The insurance required by this Section 11.3 is not intended to cover machinery, tools or equipment owned or rented by the Contractor which are utilized in the performance of the Work but not incorporated into the permanent improvements. The Contractor shall, at the Contractor's own expense, provide insurance coverage for owned or rented machinery, tools or equipment which shall be subject to the provisions of Section 11.3.7. § 11.3.2 Boiler and Machinery Insurance. The Owner shall purchase and maintain boiler and machinery insurance required by the Contract Documents or by law, which shall specifically cover such insured objects during installation and until final acceptance by the Owner; this insurance shall include interests of the Owner, Construction Manager, Contractor, Subcontractors and Sub - subcontractors in the Work, and the Owner and Contractor shall be named insureds. § 11.3.3 Loss of Use Insurance. The Owner, at the Owner's option, may purchase and maintain such insurance as will insure the Owner against loss of use of the Owner's property due to fire or other hazards, however caused. The Owner waives all rights of action against the Contractor for loss of use of the Owner's property, including consequential losses due to fire or other hazards however caused. § 11.3.4 If the Contractor requests in writing that insurance for risks other than those described herein or for other special hazards be included in the property insurance policy, the Owner shall, if possible, include such insurance, and the cost thereof shall be charged to the Contractor by appropriate Change Order. § 11.3.5 If during the Project construction period the Owner insures properties, real or personal or both, adjoining or adjacent to the site by property insurance under policies separate from those insuring the Project, or if after final payment property insurance is to be provided on the completed Project through a policy or policies other than those insuring the Project during the construction period, the Owner shall waive all rights in accordance with the terms of Section 11.3.7 for damages caused by fire or other perils covered by this separate property insurance. All separate policies shall provide this waiver of subrogation by endorsement or otherwise. § 11.3.6 Before an exposure to loss may occur, the Owner shall file with the Contractor a copy of each policy that includes insurance coverages required by this Section 11.3. Each policy shall contain all generally applicable conditions, definitions, exclusions and endorsements related to this Project. Each policy shall contain a provision that the policy will not be canceled or allowed to expire until at least 30 days' prior written notice has been given to the Contractor. § 11.3.7 Waivers of Subrogation. The Owner and Contractor waive all rights against each other and against the Construction Manager, Architect, Owner's other Contractors and own forces described in Article 6, if any, and the subcontractors, sub - subcontractors, consultants, agents and employees of any of them, for damages caused by fire or other perils to the extent covered by property insurance obtained pursuant to this Section 11.3 or other property insurance applicable to the Work, except such rights as the Owner and Contractor may have to the proceeds of such insurance held by the Owner as fiduciary. The Owner or Contractor, as appropriate, shall require of the Construction Manager, Construction Manager's consultants, Architect, Architect's consultants, Owner's separate contractors described in Article 6, if any, and the subcontractors, sub - subcontractors, agents and employees of any of them, by appropriate agreements, written where legally required for validity, similar waivers each in favor of other parties enumerated herein. The policies shall provide such waivers of subrogation by endorsement or otherwise. A waiver of subrogation shall be effective as to a person or entity even though that person or entity would otherwise have a duty of indemnification, contractual or otherwise, did not pay the insurance premium directly or indirectly, and whether or not the person or entity had an insurable interest in the property damaged. § 11.3.8 A loss insured under Owner's property insurance shall be adjusted by the Owner as fiduciary and made payable to the Owner as fiduciary for the insureds, as their interests may appear, subject to requirements of any applicable mortgagee clause and of Section 11.3.10. The Contractor shall pay Subcontractors their just shares of insurance proceeds received by the Contractor, and by appropriate agreements, written where legally required for validity, shall require Subcontractors to make payments to their Sub - subcontractors in similar manner. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 42 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 11.3.9 If required in writing by a party in interest, the Owner as fiduciary shall, upon occurrence of an insured loss, give bond for proper performance of the Owner's duties. The cost of required bonds shall be charged against proceeds received as fiduciary. The Owner shall deposit in a separate account proceeds so received, which the Owner shall distribute in accordance with such agreement as the parties in interest may reach, or in accordance with an arbitration award in which case the procedure shall be as provided in Section 4.9. If after such loss no other special agreement is made, replacement of damaged property shall be covered by appropriate Change Order. § 11.3.10 The Owner as fiduciary shall have power to adjust and settle a loss with insurers unless one of the parties in interest shall object in writing within five days after occurrence of loss to the Owner's exercise of this power; if such objection be made, arbitrators shall be chosen as provided in Section 4.9. The Owner as fiduciary shall, in that case, make settlement with insurers in accordance with directions of such arbitrators. If distribution of insurance proceeds by arbitration is required, the arbitrators will direct such distribution. § 11.3.11 Partial occupancy or use in accordance with Section 9.9 shall not commence until the insurance company or companies providing property insurance have consented to such partial occupancy or use by endorsement or otherwise. The Owner and the Contractor shall take reasonable steps to obtain consent of the insurance company or companies and shall, without mutual written consent, take no action with respect to partial occupancy or use that would cause cancellation, lapse or reduction of insurance. § 11.4 PERFORMANCE BOND AND PAYMENT BOND § 11.4.1 The Owner shall have the right to require the Contractor to furnish bonds covering faithful performance of the Contract and payment of obligations arising thereunder as stipulated in bidding requirements or specifically required in the Contract Documents on the date of execution of the Contract. § 11.4.2 Upon the request of any person or entity appearing to be a potential beneficiary of bonds covering payment of obligations arising under the Contract, the Contractor shall promptly furnish a copy of the bonds or shall permit a copy to be made. 11.5 CONTRACTOR'S WORKER'S COMPENSATION INSURANCE § 11.5.1 A copy of Contractor's Certificate of Insurance, a Certificate of Authority to self insure issued by the commission, or a coverage agreement showing statutory workers compensation insurance coverage for the Contractor's emplovees. or other Dersons Droviding services on a Project is reauired for the duration of the Project. § 11.5.2 Persons providing services on the Project ( "Subcontractor" in the Texas Labor Code 406.096) include all persons or entities performing all or part of the services the Contractor has undertaken to perform on the Project, regardless of whether that person contracted directly with the Contractor and regardless of whether that person has employees. This includes, without limitation, independent contractors, Subcontractors, leasing companies, motor carriers, owner - operators, employees of any such entity, or employees of any entity that furnishes persons to provide services to the oroiect. § 11.5.3 Services include without limitation, providing, hauling, or delivering equipment or materials, or providing labor, transportation, or other service related to a Project. Services do not include activities unrelated to the Project, such as food/beveraae vendors, office suDDly deliveries. and delivery of Dortable toilets. & 11.5.4 The Contractor must Drovide a Certificate of Coveraee to the Owner Drior to being awarded the contract. § 11.5.5 The Contractor's failure to comply with any of these provisions is a breach of Contract by the Contractor that entitles the Owner to declare the contract void if the Contractor does not remedy the breach within (10) days after receipt of notice of breach from Owner. ARTICLE 12 UNCOVERING AND CORRECTION OF WORK § 12.1 UNCOVERING OF WORK § 12.1.1 If a portion of the Work is covered contrary to the Construction Manager's or Architect's request or to requirements specifically expressed in the Contract Documents, it must, if required in writing by either, be uncovered for their observation and be replaced at the Contractor's expense without change in the Contract Time. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 43 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 12.1.2 If a portion of the Work has been covered which the Construction Manager or Architect has not specifically requested to observe prior to its being covered, the Construction Manager or Architect may request to see such Work and it shall be uncovered by the Contractor. If such Work is in accordance with the Contract Documents, costs of uncovering and replacement shall, by appropriate Change Order, be charged to the Owner. If such Work is not in accordance with the Contract Documents, the Contractor shall pay such costs unless the condition was caused by the Owner or one of the other Contractors in which event the Owner shall be responsible for payment of such costs. § 12.2 CORRECTION OF WORK § 12.2.1 The Contractor shall promptly correct Work rejected by the Construction Manager or Architect or failing to conform to the requirements of the Contract Documents, whether observed before or after Substantial Completion and whether or not fabricated, installed or completed. The Contractor shall bear costs of correcting such rejected Work, including additional testing and inspections and compensation for the Construction Manager's and Architect's services and expenses made necessary thereby. § 12.2.2 If, within one year after the date of Substantial Completion of the Work or designated portion thereof, or after the date for commencement of warranties established under Section 9.9.1, or by terms of an applicable special warranty required by the Contract Documents, any of the Work is found to be not in accordance with the requirements of the Contract Documents, the Contractor shall correct it promptly after receipt of written notice from the Owner to do so unless the Owner has previously given the Contractor a written acceptance of such condition. This period of one year shall be extended with respect to portions of Work first performed after Substantial Completion by the period of time between Substantial Completion and the actual performance of the Work. This obligation under this Section 12.2.2 shall survive acceptance of the Work under the Contract and termination of the Contract. The Owner shall give such notice promptly after discovery of the condition. § 12.2.3 The Contractor shall remove from the site portions of the Work which are not in accordance with the requirements of the Contract Documents and are neither corrected by the Contractor nor accepted by the Owner. § 12.2.4 If the Contractor fails to correct nonconforming Work within a reasonable time, the Owner may correct it in accordance with Section 2.4. If the Contractor does not proceed with correction of such nonconforming Work within a reasonable time fixed by written notice from the Architect issued through the Construction Manager, the Owner may remove it and store the salvable materials or equipment at the Contractor's expense. If the Contractor does not pay costs of such removal and storage within ten days after written notice, the Owner may upon ten additional days' written notice sell such materials and equipment at auction or at private sale and shall account for the proceeds thereof, after deducting costs and damages that should have been borne by the Contractor, including compensation for the Construction Manager's and Architect's services and expenses made necessary thereby. If such proceeds of sale do not cover costs which the Contractor should have borne, the Contract Sum shall be reduced by the deficiency. If payments then or thereafter due the Contractor are not sufficient to cover such amount, the Contractor shall pay the difference to the Owner. § 12.2.5 The Contractor shall bear the cost of correcting destroyed or damaged construction, whether completed or partially completed, of the Owner or other Contractors caused by the Contractor's correction or removal of Work which is not in accordance with the requirements of the Contract Documents. § 12.2.6 Nothing contained in this Section 12.2 shall be construed to establish a period of limitation with respect to other obligations which the Contractor might have under the Contract Documents. Establishment of the time period of one year as described in Section 12.2.2 relates only to the specific obligation of the Contractor to correct the Work, and has no relationship to the time within which the obligation to comply with the Contract Documents may be sought to be enforced, nor to the time within which proceedings may be commenced to establish the Contractor's liability with respect to the Contractor's obligations other than specifically to correct the Work. § 12.3 ACCEPTANCE OF NONCONFORMING WORK § 12.3.1 If the Owner prefers to accept Work which is not in accordance with the requirements of the Contract Documents, the Owner may do so instead of requiring its removal and correction, in which case the Contract Sum will be reduced as appropriate and equitable. Such adjustment shall be effected whether or not final payment has been made. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 44 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) ARTICLE 13 MISCELLANEOUS PROVISIONS § 13.1 GOVERNING LAW § 13.1.1 The Contract shall be governed by the law of the place where the Project is located. § 13.2 SUCCESSORS AND ASSIGNS § 13.2.1 The Owner and Contractor respectively bind themselves, their partners, successors, assigns and legal representatives to the other party hereto and to partners, successors, assigns and legal representatives of such other party in respect to covenants, agreements and obligations contained in the Contract Documents. Neither party to the Contract shall assign the Contract as a whole without written consent of the other. If either party attempts to make such an assignment without such consent, that party shall nevertheless remain legally responsible for all obligations under the Contract. § 13.3 WRITTEN NOTICE § 13.3.1 Written notice shall be deemed to have been duly served if delivered in person to the individual or a member of the firm or entity or to an officer of the corporation for which it was intended, or if delivered at or sent by registered or certified mail to the last business address known to the party giving notice. § 13.4 RIGHTS AND REMEDIES § 13.4.1 Duties and obligations imposed by the Contract Documents and rights and remedies available thereunder shall be in addition to and not a limitation of duties, obligations, rights and remedies otherwise imposed or available by law. § 13.4.2 No action or failure to act by the Owner, Construction Manager, Architect or Contractor shall constitute a waiver of a right or duty afforded them under the Contract, nor shall such action or failure to act constitute approval of or acquiescence in a breach thereunder, except as may be specifically agreed in writing. § 13.5 TESTS AND INSPECTIONS § 13.5.1 Tests, inspections and approvals of portions of the Work required by the Contract Documents or by laws, ordinances, rules, regulations or orders of public authorities having jurisdiction shall be made at an appropriate time. Unless otherwise provided, the Contractor shall make arrangements for such tests, inspections and approvals with an independent testing laboratory or entity acceptable to the Owner, or with the appropriate public authority, and shall bear all related costs of tests, inspections and approvals. The Contractor shall give the Construction Manager and Architect timely notice of when and where tests and inspections are to be made so the Construction Manager and Architect may observe such procedures. The Owner shall bear costs of tests, inspections or approvals which do not become requirements until after bids are received or negotiations concluded. If requested by Owner, Contractor shall coordinate with testing laboratory provide adequate time and notice for the testing laboratory perform testing in accordance with the requirements of the Work. No inspection performed or failed to be performed by Owner hereunder shall be a waiver of any of Contractor's obligations hereunder or is to be construed as an approval or acceptance of the Work or any part thereof. § 13.5.2 If the Construction Manager, Architect, Owner or public authorities having jurisdiction determine that portions of the Work require additional testing, inspection or approval not included under Section 13.5.1, the Construction Manager and Architect will, upon written authorization from the Owner, instruct the Contractor to make arrangements for such additional testing, inspection or approval by an entity acceptable to the Owner, and the Contractor shall give timely notice to the Construction Manager and Architect of when and where tests and inspections are to be made so the Construction Manager and Architect may observe such procedures. The Owner shall bear such costs except as provided in Section 13.5.3. § 13.5.3 If such procedures for testing, inspection or approval under Sections 13.5.1 and 13.5.2 reveal failure of the portions of the Work to comply with requirements established by the Contract Documents, the Contractor shall bear all costs made necessary by such failure including those of repeated procedures and compensation for the Construction Manager's and Architect's services and expenses. § 13.5.4 Required certificates of testing, inspection or approval shall, unless otherwise required by the Contract Documents, be secured by the Contractor and promptly delivered to the Construction Manager for transmittal to the Architect. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 45 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 13.5.5 If the Construction Manager or Architect is to observe tests, inspections or approvals required by the Contract Documents, the Construction Manager or Architect will do so promptly and, where practicable, at the normal place of testing. § 13.5.6 Tests or inspections conducted pursuant to the Contract Documents shall be made promptly to avoid unreasonable delay in the Work. § 13.6 INTEREST § 13.6.1 Payments due and unpaid under the Contract Documents shall bear interest from the date payment is due at such rate as the parties may agree upon in writing or, in the absence thereof, at the legal rate prevailing from time to time at the place where the Project is located. § 13.7 COMMENCEMENT OF STATUTORY LIMITATION PERIOD § 13.7.1 As between the Owner and Contractor: .1 Before Substantial Completion. As to acts or failures to act occurring prior to the relevant date of Substantial Completion, any applicable statute of limitations shall commence to run and any alleged cause of action shall be deemed to have accrued in any and all events not later than such date of Substantial Completion; .2 Between Substantial Completion and Final Certificate for Payment. As to acts or failures to act occurring subsequent to the relevant date of Substantial Completion and prior to issuance of the final Certificate for Payment, any applicable statute of limitations shall commence to run and any alleged cause of action shall be deemed to have accrued in any and all events not later than the date of issuance of the final Certificate for Payment; and .3 After Final Certificate for Payment. As to acts or failures to act occurring after the relevant date of issuance of the final Certificate for Payment, any applicable statute of limitations shall commence to run and any alleged cause of action shall be deemed to have accrued in any and all events not later than the date of any act or failure to act by the Contractor pursuant to any warranty provided under Section 3.5, the date of any correction of the Work or failure to correct the Work by the Contractor under Section 12.2, or the date of actual commission of any other act or failure to perform any duty or obligation by the Contractor or Owner, whichever occurs last. 13.8 EQUAL OPORTUNITY 13.8.1 The Contractor and the Contractor's Subcontractors shall not discriminate aeainst anv emnlovee or applicant for employment because of race, religion, color, sex or national origin. Contractor shall take affirmative action to ensure that applicants are employed, and employees are treated during employment without regard to their race, religion, color, sex, or national origin. The Contractor agrees es to post in conspicuous places, available to employees and applicants, notices setting forth the nondiscrimination policies. 13.8.2 The Contractor and the Contractor's Subcontractors, shall in all solicitations or advertisements for employees placed by them or on their behalf, state that all qualified applicants will receive consideration for employment without regard to race, religion, color, sex, or national origin. ARTICLE 14 TERMINATION OR SUSPENSION OF THE CONTRACT § 14.1 TERMINATION BY THE CONTRACTOR § 14.1.1 The Contract may terminate the Contract if the Work is stopped for a period of 30 days through no act or fault of the Contractor or a Subcontractor, Sub - subcontractor or their agents or employees or any other persons performing portions of the Work under contract with the Contractor, for any of the following reasons: .1 issuance of an order of a court or other public authority having jurisdiction; .2 an act of government, such as a declaration of national emergency, making material unavailable; .3 because the Construction Manager or Architect has not issued a Certificate for Payment and has not notified the Contractor of the reason for withholding certification as provided in Section 9.4.2, or because the Owner has not made payment on a Certificate for Payment within the time stated in the Contract Documents; AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 46 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) .4 if repeated suspensions, delays or interruptions by the Owner as described in Section 14.3 constitute in the aggregate more than 100 percent of the total number of days scheduled for completion, or 120 days in any 365 -day period, whichever is less; or .5 the Owner has failed to furnish to the Contractor promptly, upon the Contractor's request, reasonable evidence as required by Section 2.2.1. § 14.1.2 If one of the above reasons exists, the Contractor may, upon seven additional days' written notice to the Owner, Construction Manager and Architect, terminate the Contract and recover from the Owner payment for Work executed and for proven loss with respect to materials, equipment, tools, and construction equipment and machinery, including reasonable overhead, profit and damages. § 14.1.3 If the Work is stopped for a period of 60 days through no act or fault of the Contractor or a Subcontractor or their agents or employees or any other persons performing portions of the Work under contract with the Contractor because the Owner has persistently failed to fulfill the Owner's obligations under the Contract Documents with respect to matters important to the progress of the Work, the Contractor may, upon seven additional days' written notice to the Owner, Construction Manager and Architect, terminate the Contract and recover from the Owner as provided in Section 14.1.2. § 14.2 TERMINATION BY THE OWNER FOR CAUSE § 14.2.1 The Owner may terminate the Contract if the Contractor: .1 persistently or repeatedly refuses or fails to supply enough properly skilled workers or proper materials; .2 fails to make payment to Subcontractors for materials or labor in accordance with the respective agreements between the Contractor and the Subcontractors; .3 persistently disregards laws, ordinances, or rules, regulations or orders of a public authority having jurisdiction; or .4 otherwise is guilty of substantial breach of a provision of the Contract Documents. § 14.2.2 When any of the above reasons exist, the Owner, after consultation with the Construction Manager, and upon certification by the Architect that sufficient cause exists to justify such action, may without prejudice to any other rights or remedies of the Owner and after giving the Contractor and the Contractor's surety, if any, seven days' written notice, terminate employment of the Contractor and may, subject to any prior rights of the surety: .1 take possession of the site and of all materials, equipment, tools, and construction equipment and machinery thereon owned by the Contractor; .2 accept assignment of subcontracts pursuant to Section 5.4; and .3 finish the Work by whatever reasonable method the Owner may deem expedient. § 14.2.3 When the Owner terminates the Contract for one of the reasons stated in Section 14.2.1, the Contractor shall not be entitled to receive further payment until the Work is finished. § 14.2.4 If the unpaid balance of the Contract Sum exceeds costs of finishing the Work, including compensation for the Construction Manager's and Architect's services and expenses made necessary thereby, such excess shall be paid to the Contractor. If such costs exceed the unpaid balance, the Contractor shall pay the difference to the Owner. The amount to be paid to the Contractor or Owner, as the case may be, shall, upon application, be certified by the Architect after consultation with the Construction Manager, and this obligation for payment shall survive termination of the Contract. § 14.3 SUSPENSION BY THE OWNER FOR CONVENIENCE § 14.3.1 The Owner may, without cause, order the Contractor in writing to suspend, delay or interrupt the Work in whole or in part for such period of time as the Owner may determine. § 14.3.2 An adjustment shall be made for increases in the cost of performance of the Contract, including profit on the increased cost of performance, caused by suspension, delay or interruption. No adjustment shall be made to the extent: .1 that performance is, was or would have been so suspended, delayed or interrupted by another cause for which the Contractor is responsible; or .2 that an equitable adjustment is made or denied under another provision of this Contract. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 47 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) § 14.3.3 Adjustments made in the cost of performance may have a mutually agreed fixed or percentage fee. AIA Document A201 /CMaTM — 1992. Copyright © 1992 by The American Institute of Architects. All rights reserved. WARNING: This AIA" Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, 48 may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235) Certification of Document's Authenticity AIA® Document D401 TM —2003 I, Lee Lewis, hereby certify, to the best of my knowledge, information and belief, that I created the attached final document simultaneously with this certification at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 from AIA Contract Documents software and that in preparing the attached final document I made no changes to the original text of AIA Document A201 /CMaTM — 1992 - General Conditions of the Contract for Construction where the Construction Manager is NOT a Constructor, as published by the AIA in its software, other than changes shown in the attached final document by underscoring added text and striking over deleted text. (Signed) (Title) (Dated) AIA Document D401 TM — 2003. Copyright © 1992 and 2003 by The American Institute of Architects. All rights reserved. WARNING: This AIA Document is protected by U.S. Copyright Law and International Treaties. Unauthorized reproduction or distribution of this AIA Document, or any portion of it, may result in severe civil and criminal penalties, and will be prosecuted to the maximum extent possible under the law. This document was produced by AIA software at 09:07:44 on 07/06/2004 under Order No. 1000123364_1 which expires on 6/11/2005, and is not for resale. User Notes: (4096555235)