Item 9BCity of Southlake, Texas
MEMORANDUM
August 5, 2008
To: Shana Yelverton, City Manager
From: Robert H. Price, P.E., Public Works Director
Subject: Consider a Commercial Developer's Agreement with Keller
Watermere, L.P., for South Village at Watermere, located south of
West Southlake Boulevard between Pearson Road and Davis
Boulevard.
Action
Requested: Authorize a Commercial Developer's Agreement with Keller Watennere,
L.P., for South Village at Watermere, located south of West Southlake
Boulevard between Pearson Road and David Boulevard.
Background
Information: The developer will construct approximately 6,000 LF of public waterline,
3,500 LF of public sewerline, 2,000 LF of public storm drain, and 1,300
LF of public pavement. This developer's agreement covers the
construction of these public improvements.
The project also includes parks and recreation facilities to be provided by
the developer. These include an 8" paved pathway on the east side of
Watermere Drive, 1.25 miles of 5' paved trails on the west side of
Watermere Drive connecting the public parkland in Watermere at
Southlake to Union Church Road, a 6' paved sidewalk along Union
Church Road, and 6 acres of private open space.. The developer will also
provide recreationl facilities, including two lighted tennis courts, a fishing
pier, an outdoor neighborhood pool, a horseshoe pit, a pavilion, and a
playground.
Financial
Considerations: The Master Thoroughfare Plan requires construction of a two -lane
collector through the development between West Southlake Boulevard and
Union Church Road. The standard pavement section requirement for this
section is thirty -six (36) feet face of curb to face of curb, six (6) feet wider
and two (2) inches thicker than a typical residential street.
The developer is requesting that the City participate in the oversizing of
the pavement in an amount not to exceed $49,713.00. Please see the
attached letter detailing the request.
The developer is also making downstream drainage improvements with
the installation of 2 — 6' x 3' and 1 — 5' x 3' box culverts under Union
Church Road and grading the immediate downstream channel to
Edgebrook Drive. These improvements will support the development and
alleviate existing drainage issues along Union Church.
The developer is requesting that the City participate in the engineering,
construction and surveying of these off -site drainage improvements by
reimbursing the developer to the extent of 29.5% of actual costs not to
exceed $59,306.00. This request is also detailed in the attached letter from
GSWW.
Citizen Input/
Board Review: None
Legal
Review: This is the City's standard commercial developer's agreement, originally
drafted by the City Attorney.
Alternatives: The City Council may approve it, deny it or modify it.
Supporting
Documents: Letter dated July 30, 2008 from GSWW, Inc.
Agreement
Location Map
Utility Plan
Staff
Recommendation: Authorize a Commercial Developer's Agreement with Keller Watermere,
L.P., for South Village at Watermere, located south of West Southlake
Boulevard between Pearson road and David Boulevard.
Staff
Contact: Bob Price, P.E., Public Works Director
Gordon Mayer, P.E., Deputy Director of Public Works
Cheryl Taylor, P.E. Civil Engineer
Page 2 of 2
July 30, 2008
G SWW, I
L: vill�nvwontneriMl tngavers ■ Mariners
DaNas ■ Fort Worth . Midland Austin ■ Houston
Predecessor Firms. Gutierrez, Smouse, Wilmut & Assoc., Inc.
Washington & Associates, Inc.
Mr. Gordon Mayer, P.E.
City Engineer - City of Southlake
1404 Main Street, 'Suite 320
Southlake, Texas 76092
Ref: Request for City Participation for Offsite Drainage Improvements and Reimbursement for Pavement Widening
of Watermere Drive in Conjunction with Development of South Village at Watermere
(Revision to July 25, 2008 Participation Letter - Remove Request for Waiver of City Admin. & Inspection Fees)
GSWW, Inc. Job No.: 04T7 -002
Dear Mr. Mayen
Mr. Richard Simmons has requested that we provide you with a summary of costs associated with the proposed offsite drainage
improvements and costs associated with the pavement widening (31' to 37') of Watermere Drive For South Village at Watermere.
The developer is requesting City participation for offsite drainage improvements in the amount of $59,306.00 and reimbursement
from the City in the amount of $49,713,00 for the pavement widening of Watermere Drive.
The total cost of the oftsite drainage improvements is estimated at $201,154.40. The total cost of the pavement widening of
Watermere Drive is estimated at $49,713.00. Outlined below is a summary of the developer's cost participatlonlreimbursement
request for the offsite drainage improvements and for the pavement widening of Watermere Drive.
Cost Participation Items for Offsite Drainage Improvements Developer Portion City Portion
Engineering - (Refer to GSWW, Inc. Civil Services Agreement) $22,4 00.00 $9,6 04.04
Surveying - Design Survey (Refer to Peiser Surveying Co. Letter) $1,050.04 $450.00
Surveying - Constr. Staking (Estimated by GSWW, Inc.) $1,693.00 $725.00
Offsite S. D. Improvements Cost (Refer to GSWW, Inc. Cost Opinion) $113,884.00 $47,322.00
Bonds — 2 rJ100% Const. Cost Estimated by GSWW Inc. $ $1,209.00
Summary of Cost Participation for Offsite Drainage Improvements $141,848.00 $59,306.00
Requested City Participation - $59,306.00 ( +1 -30% of Total Cost)
Developer's Portion - $141,648.00 ( +1 -70`Yv of Total Cost)
Cost Reimbursement Items for Pavement Widenina of Watermere Drive [from 31' to 371 City Portion
Pavement Widening Cost (refer to GSWW, Inc. Cost Opinion) $46,510.00
Additional Excavation Cost (Estimated by GSWW, €nc.: +1 -680 cy @ $3lcy) $2,040.00
Bands - 2 yr. / 100% Const. Cost (Estimated by GSWW, Inc.) $1,163.00
Total Cost of Pavement Widening of Watermere Drive $49,713.00
Requested Reimbursement from City (100% of Total Cost) $49,713.00
It is also important to note that construction of the offsite drainage improvements in conjunction with the Watermere
detention facilities will reduce the storm water runoff flows at southeast corner of South Village at Watermere at Union
Church Road by 66.9% in the 2 year storm event (from 124 cfs to 41 cfs), by 53.7% in the 10 year storm event (from 313
cfs to 145 cfs) and by 58.5% in the 100 year storm event (662 cfs to 275 cfs). As required by the City of South lake Public
Works Department, the Soil Conservation Service (SCS) Unit hlydrograph Method with a (three) 3 hour storm duration
was used to compute the storm water runoff hydrographs for routing through the on - site detention facilities for the
various storm events identified above.
Attached with this letter are copies of the supporting documents that further itemize the costs associated with the developer's
request (i.e. GSWW, Inc. Civil Services Agreement, GSWW, Inc. Updated Cost Opinions and Peiser Surveying Co. Letter). This
information is provided to you for use in preparing the developer's agreement for South Village at Watermere.
10701 Corporate Drive Suite 203 . Stafford, Texas 77477 . 281.980.7705 . 281.980.0455 Fax . www.gsw- inc.com
Page 2
July 30, 2008
(Revision to July 25, 2008 City Participation I Reimbursement Letter) — South Village at Watermere
Please do not hesitate to contact our office at (817) 306 -1444 or (281) 980 -7705 if you have any questions.
Sincerely,
q w'� T
Joseph T. Reue, P.E.
Associate /Project Manager
Attachments:
(1) GSWW, Inc. Civil Services Agreement for Offsite Drainage Improvements
(2) GSWW, Inc. Updated Cost Opinion for Offste Drainage Improvements
(3) GSWW, Inc. Updated Cost Opinion for Pavement Widening of Watermare Drive
(4) Letter from Pei ser Surveying Co. for Offs ite Design Survey
Cc: Richard E. Simmons, Southlake Watermark Holding, LP.
South Village at Watermere
COMMERCIAL DEVELOPER AGREEMENT
An agreement between the City of Southlake, Texas, hereinafter referred to as the
"City ", and Keller Watermere, L.P., hereinafter referred to as the "Developer ", of South
Village at Watermere, hereinafter referred to as "Addition" to the City of Southlake,
Tarrant County, Texas, for the installation of certain community facilities located therein,
and to provide city services thereto. It is understood by and between the parties that
this Agreement is applicable to the Addition (a commercial development) and to the off -
site improvements necessary to support the Addition.
GENERAL REQUIREMENTS
A. It is agreed and understood by the parties hereto that the Developer shall
employ a civil engineer licensed to practice in the State of Texas for the
design and preparation of the plans and specifications for the construction
of all facilities covered by this Agreement.
B. The Developer will present to the City either a cash escrow, Letter of
Credit, performance bond and payment bond acceptable to the City
guaranteeing and agreeing to pay an amount equal to 100% of the value
of the construction cost of all the public facilities to be constructed by the
Developer, and providing for payment to the City of such amounts, up to
the total remaining amounts required for the completion of the public
facilities if the Developer fails to complete the work within two (2) years of
the signing of this Agreement between the City and Developer. All bonds
shall be issued by a Best -rated bonding company. All letters of credit
must meet the Requirements for Irrevocable Letter of Credit attached
hereto and incorporated herein.
The value of the performance bond, letter of credit or cash escrow will
reduce at a rate consistent with the amount of work that has been
completed by the Developer and accepted by the City. Performance and
payment bond, letter of credit or cash escrow from the prime contractor(s)
or other entity reasonably acceptable to the City, hereinafter referred to as
Contractor, will be acceptable in lieu of Developer's obligations specified
above.
C. The Developer agrees to furnish to the City either maintenance bonds,
letter of credit or cash escrow amounting to 100% of the cost of
construction of underground public utilities and 100% for the paving.
These maintenance bonds, letter of credit or cash escrow will be for a
period of two (2) years and will be issued prior to the final City acceptance
of the Addition. The maintenance bonds, letter of credit or cash escrow
will be supplied to the City by the contractors performing the work, and the
Page 1 of 18
City will be named as the beneficiary if the contractors fail to perform any
required maintenance.
D. It is further agreed and understood by the parties hereto that upon
acceptance by the City, title to all facilities and improvements mentioned
herein above which are intended to be public facilities shall be vested in
the City, and Developer hereby relinquishes any right, title, or interest in
and to said facilities or any part thereof. It is further understood and
agreed that until the City accepts such improvements, the City shall have
no liability or responsibility in connection with any such facilities.
Acceptance of the facilities for this provision and for the entire Agreement
shall occur at such time that the City, through its City Manager or his duly
appointed representative, provides Developer with a written
acknowledgement that all facilities are complete, have been inspected and
approved, and are being accepted by the City.
E. On all public facilities included in this Agreement for which the Developer
awards his own construction contract, Developer agrees to the following
procedure:
1. Developer agrees to pay the following:
a. Inspection fees equal to three percent (3 %) of the cost of the
water , street, drainage and sanitary sewer facilities, on all
facilities included in this agreement for which Developer
awards his or her own construction contract, to be paid prior
to construction of each phase and based on actual bid
construction cost;
b. Administrative Processing Fee equal to two percent (2 %) of
the cost of water, street, drainage and sanitary sewer
facilities, on all facilities included in this Agreement for which
Developer awards his or her own construction contract, to be
paid prior to construction of each phase and based on actual
bid construction cost;
C. Trench testing (95% Standard);
d. The additional charge for inspections during Saturday,
Sunday, holidays, and after normal working hours;
e. Any charges for retesting as a result of failed tests;
f. All gradation tests required to insure proper cement and /or
lime stabilization.
Page 2 of 18
2. The City agrees to bear the expense of:
a. All nuclear density tests on the roadway subgrade (95%
Standard);
b. Technicians time for preparing concrete cylinders; and
C. Concrete cylinder tests and concrete coring samples.
The City can delay connection of buildings to service lines or water
mains constructed under this Agreement until said water mains and
service lines have been completed to the satisfaction of and
acceptance by the City.
F. The Developer will be responsible for mowing all grass and weeds and
otherwise reasonably maintaining the aesthetics of all land and lots in said
Addition which have not been sold to third parties. After fifteen (15) days
written notice, should the Developer fail in this responsibility, the City may
contract for this service and bill the Developer for reasonable costs. Such
amount shall become a lien upon all real property of the Addition so
maintained by the City, and not previously conveyed to other third parties,
120 days after Developer has notice of costs.
G. Any guarantee of payment instrument (Performance Bond, Letter of
Credit, etc.) submitted by the Developer or Contractor on a form other
than the one which has been previously approved by the City as
"acceptable" shall be submitted to the City Attorney and this Agreement
shall not be considered in effect until such City Attorney has approved the
instrument. Approval by the City shall not be unreasonably withheld or
delayed.
H. Any surety company through which a bond is written shall be a surety
company duly authorized to do business in the State of Texas, provided
that the City, through the City Manager, shall retain the right to reject any
surety company as a surety for any work under this or any other
Developer's Agreement within the City regardless of such company's
authorization to do business in Texas. Approval by the City shall not be
unreasonably withheld or delayed.
The Developer agrees to fully comply with the terms and conditions of all
other applicable development regulations and ordinances of the City.
J. The Developer agrees that the completed project will be constructed in
conformance with the Development Site Plan, Construction Plans and
other permits or regulatory authorizations granted by the City during the
development review process.
Page 3 of 18
II. FACILITIES
A. ON -SITE WATER
The Developer hereby agrees to install water facilities to service lots as
shown on the final plat of the Addition. Water facilities will be installed in
accordance with plans and specifications to be prepared by the
Developer's engineer and released by the City. Further, the Developer
agrees to complete this installation in accordance with Ordinance No. 170
and shall be responsible for all construction costs, materials and
engineering. In the event that certain water lines are to be oversized
because of City requirements, the City will reimburse the Developer for the
oversize cost greater than the cost of an 8" line. Additionally, the City
agrees to provide temporary water service at Developer's request and
expense, for construction, testing and irrigation purposes only, to
individual lots during the construction of buildings, even though sanitary
sewer service may not be available to the buildings.
B. DRAINAGE
Developer hereby agrees to construct the necessary drainage facilities
within the Addition. These facilities shall be in accordance with the plans
and specifications to be prepared by Developer's engineers, released by
the Director of Public Works, the City, and made part of the final plat as
approved by the Planning and Zoning Commission. The Developer
hereby agrees to fully comply with all EPA and TNRCC requirements
relating to the planning, permitting and management of storm water which
may be in force at the time that development proposals are being
presented for approval by the City.
C. STREETS
The street construction in the Addition will be installed in accordance with
plans and specifications to be prepared by the Developer's engineer and
released by the Director of Public Works.
1. The Developer will be responsible for:
a) Installation and two year operation of street lights, which is
payable to the City prior to final acceptance of the Addition;
or an agreement with utility provider stating that no charge
will be made for street lights for the two -year duration.
b) Installation of all street signs designating the names of the
streets inside the Addition, said signs to be of a type, size,
Page 4 of 18
color and design standard generally employed by the
Developer and approved by the City in accordance with City
ordinances;
C) Installation of all regulatory signs recommended based upon
the Manual on Uniform Traffic Control Devices as prepared
by the Developer's engineer by an engineering study or
direction of the Director of Public Works. It is understood
that Developer may put in signage having unique
architectural features, however, should the signs be moved
or destroyed by any means, the City is only responsible for
replacement of standard signage.
2. Watermere Drive is shown as a collector street on the Master
Thoroughfare Plan (Res 05 -027). The pavement width (37'B -B) of
the collector street exceeds the pavement width (31'13-13) of the
standard local street required by the City's development standards
by 6'. The City will reimburse the developer for actual construction
cost of the additional street paving width in an amount not to exceed
$49,713 upon final acceptance of construction and when funds are
available.
3. All street improvements will be subject to inspection and approval by
the City. No work will begin on any street included herein prior to
complying with the requirements contained elsewhere in this
Agreement. All water, sanitary sewer, and storm drainage utilities
which are anticipated to be installed within the street or within the
street right -of -way will be completed prior to the commencement of
street construction on the specific section of street in which the utility
improvements have been placed or for which they are programmed.
It is understood by and between the Developer and the City that this
requirement is aimed at substantial compliance with the majority of
the pre - planned facilities.
It is understood that in every construction project a decision later
may be made to realign a line or service which may occur after
construction has commenced. The Developer has agreed to advise
the City Director of Public Works as quickly as possible when such
a need has been identified and to work cooperatively with the City
to make such utility change in a manner that will be least disruptive
to street construction or stability.
D. ON -SITE SANITARY SEWER FACILITIES
The Developer hereby agrees to install sanitary sewage collection facilities
to service lots as shown on the final plat of the Addition. Sanitary sewer
facilities will be installed in accordance with the plans and specifications to
Page 5 of 18
be prepared by the Developer's engineer and released by the City.
Further, the Developer agrees to complete this installation in compliance
with all applicable city ordinances, regulations and codes and shall be
responsible for all construction costs, materials, engineering, permits and
Impact Fees. In the event that certain sewer lines are to be oversized
because of City requirements, the City will reimburse the Developer for the
oversize cost greater than the cost of an 8" line.
E. EROSION CONTROL
During construction of the Addition and after the streets have been
installed, the Developer agrees to keep the streets free from soil build -up.
The Developer agrees to use soil control measures, such as those
included in NCTCOG STANDARD SPECIFICATIONS FOR PUBLIC
WORKS CONSTRUCTION, DIVISION 1000 EROSION AND SEDIMENT
CONTROL, to prevent soil erosion. It will be the Developer's responsibility
to present to the Director of Public Works a soil control development plan
that will be implemented for this Addition. When in the opinion of the
Director of Public Works there is sufficient soil build -up on the streets or
other drainage areas and notification has been given to the Developer, the
Developer will have seventy -two (72) hours to clear the soil from the
affected areas. If the Developer does not remove the soil within 72 hours,
the City may cause the soil to be removed either by contract or City forces
and place the soil within the Addition at the contractor's expense. All fees
owed to the City will be collected prior to acceptance of the Addition.
After construction of the Addition and prior to acceptance by the City, the
Developer agrees to have a permanent erosion control plan prepared and
approved by the Director of Public Works and have the plan installed and
working, effectively, in the opinion of the Director of Public Works. This
erosion control will prevent soil erosion from the newly created lot /lots
from washing into street rights of way, drainage ways or other private
property.
F. AMENITIES
It is understood by and between the City and Developer that the Addition
may incorporate a number of unique amenities and aesthetic
improvements such as ponds, aesthetic lakes, unique landscaping, walls,
and may incorporate specialty signage and accessory facilities. The
Developer agrees to accept responsibility for the construction and
maintenance of all such aesthetic or specialty items such as walls,
vegetation, signage, landscaping, street furniture, pond and lake
improvements until such responsibility is turned over to a homeowners
association.
Page 6 of 18
G. USE OF PUBLIC RIGHT -OF -WAY
It is understood by and between the City and Developer that the
Developer may provide unique amenities within public right -of -way, such
as landscaping, irrigation, lighting, etc., for the enhancement of the
Addition. The Developer agrees to maintain these amenities until such
responsibility is turned over to a homeowners association. The Developer
understands that the City shall not be responsible for the replacement of
these amenities under any circumstances and further agrees to indemnify
and hold harmless the City from any and all damages, loss or liability of
any kind whatsoever by reason of injury to property or third person
occasioned by its use of the public right -of -way with regard to these
improvements and the Developer shall, at his own cost and expense,
defend and protect the City against all such claims and demands.
H. START OF CONSTRUCTION
Before the construction of the water, sewer, streets or drainage facilities
can begin, the following must take place:
1. Approved payment and performance bonds must be submitted to
the City in the name of the City prior to commencement of any
work.
2. At least six (6) sets of construction plans to be stamped "Released
for Construction" by the Director of Public Works must be
submitted.
3. All fees required to be paid to the City.
4. Developer Agreement must be executed by all parties.
5. The Developer, or Contractor, shall furnish to the City a policy of
general liability insurance, naming the City as co- insured, prior to
commencement of any work. All insurance must meet the
Requirements of Contractor's Insurance attached hereto and
incorporated herein.
6. A Pre - Construction Meeting to be held with all Contractors, major
Sub - Contractors, Utilities and appropriate Government Agencies.
III. GENERAL PROVISIONS
A. INDEMNIFICATION
Page 7 of 18
DEVELOPER COVENANTS AND AGREES TO INDEMNIFY AND DOES
HEREBY INDEMNIFY, HOLD HARMLESS AND DEFEND CITY, ITS
OFFICERS, AGENTS, SERVANTS AND EMPLOYEES, FROM AND
AGAINST ANY AND ALL CLAIMS OR SUITS FOR PROPERTY
DAMAGE OR LOSS AND /OR PERSONAL INJURY, INCLUDING
DEATH, TO ANY AND ALL PERSONS, OF WHATSOEVER KIND OR
CHARACTER, WHETHER REAL OR ASSERTED, (INCLUDING,
WITHOUT LIMITATION, REASONABLE FEES AND EXPENSES OF
ATTORNEYS, EXPERT WITNESSES AND OTHER CONSULTANTS),
ARISING OUT OF OR IN CONNECTION WITH, DIRECTLY OR
INDIRECTLY, THE CONSTRUCTION, MAINTENANCE, OCCUPANCY,
USE, EXISTENCE OR LOCATION OF SAID IMPROVEMENT OR
IMPROVEMENTS, AND SHALL FURTHER BE LIABLE FOR INJURY
OR DAMAGE TO CITY PROPERTY, ARISING OUT OF OR IN
CONNECTION WITH ANY AND ALL ACTS OR OMISSIONS OF
DEVELOPER, ITS OFFICERS, AGENTS, SERVANTS, EMPLOYEES,
CONTRACTORS, SUBCONTRACTORS, LICENSEES, INVITEES OR
TRESPASSERS.
DEVELOPER AGREES TO INDEMNIFY THE CITY, ITS OFFICERS AND
EMPLOYEES FOR ANY DAMAGES, CLAIMS OR LIABILITIES
ARISING FROM THE NEGLIGENT ACT OR OMISSION, OR OF THE
CONCURRENT NEGLIGENT ACT OR OMISSION, OF THE CITY, ITS
OFFICERS AND EMPLOYEES.
B. Venue of any action brought hereunder shall be in Fort Worth, Tarrant
County, Texas.
C. Approval by the Director of Public Works or other City employee of any
plans, designs or specifications submitted by the Developer pursuant to
this Agreement shall not constitute or be deemed to be a release of the
responsibility and liability of the Developer, his engineer, employees,
officers or agents for the accuracy and competency of their design and
specifications. Such approval shall not be deemed to be an assumption of
such responsibility and liability by the City for any defect in the design and
specifications prepared by the consulting engineer, his officers, agents,
servants or employees, it being the intent of the parties that approval by
the Director of Public Works signifies the City's approval on only the
general design concept of the improvements to be constructed. In this
connection, the Developer shall for a period of two (2) years after the
acceptance by the City of the completed construction project, indemnify
and hold harmless the City, its officers, agents, servants and employees,
from any loss, damage, liability or expense on account of damage to
property and injuries, including death, to any and all persons which may
arise out of any defect, deficiency or negligence of the engineer's designs
Page 8 of 18
and specifications incorporated into any improvements constructed in
accordance therewith, and the Developer shall defend at his own expense
any suits or other proceedings brought against the City, its officers,
agents, servants or employees, or any of them, on account thereof, to pay
all expenses and satisfy all judgments which may be incurred by or
rendered against them or any of them in connection herewith.
D. This Agreement or any part herein, or any interest herein, shall not be
assigned by the Developer without the express written consent of the City
Manager, which shall not be unreasonably withheld or delayed.
E. On all facilities included in this Agreement for which the Developer awards
his or her own construction contract, the Developer agrees to employ a
construction contractor who is approved by the City, and whose approval
shall not be unreasonably withheld or delayed, said contractor to meet
City and statutory requirements for being insured, licensed and bonded to
do work in public projects and to be qualified in all respects to bid on
public projects and to be qualified in all respects to bid on public projects
of a similar nature.
In addition, the Developer, or Contractor shall furnish the payment and
performance bonds in the name of the City prior to the commencement of
any work hereunder and shall also furnish to the City a policy of general
liability insurance.
F. Work performed under the Agreement shall be completed within two (2)
years from the date thereof. In the event the work is not completed within
the two (2) year period, the City may, at its election, draw down on the
performance bond, letter of credit or other security provided by Developer
and complete such work at Developer's expense; provided, however, that
if the construction under this Agreement shall have started within the two
(2) year period, the City may agree to renew the Agreement with such
renewed Agreement to be in compliance with the City policies in effect at
that time.
G. Prior to final acceptance of the Addition, the Developer shall provide to the
City three (3) copies of Record Drawings of the Addition, showing the
facilities as actually constructed.
H. Such drawings will be stamped and signed by a registered professional
civil engineer. In addition, the Developer shall provide electronic files
showing the grading plan and drainage area map; the plan and profile of
the sanitary sewer, storm drain, roadway and waterline; all lot lines, and
tie in to the state Plane Coordinate System.
Page 9 of 18
IV. OTHER ISSUES
A. DOWN STREAM CRITICAL STRUCTURE FEE
The development flows to the downstream critical drainage structure # 18.
The fee for this structure is $212.61 /acre. The total fee for this
development ($212.61 /acre X 32.00 acres) is $6,803.52.
B. PARK IMPROVEMENTS AND FEES
The developer shall:
A. Pay park dedication fees in the amount of $90,000.
B. In addition, to meet the full park dedication requirement,
provide 6 acres of private open space.
Prior to final acceptance of civil improvements, developer shall:
Complete the construction of an 8' paved pathway as shown on the
east side of Watermere Drive; 1.25 miles of 5' wide paved trails on
the west side of Watermere Drive and through the provided open
space which will provide connectivity from FM 1709 and the public
parkland in Phase I to Union Church Road on the southern edge of
the development; and a 6' paved sidewalk along Union Church
Road as part of the 2005 Southlake Pathways Plan.
Developer agrees to:
Complete recreational facilities in the form of two (2) lighted tennis
courts, a fishing pier, an outdoor neighborhood pool, a horseshoe
pit, a pavilion, and a playground. If developer does not complete
these improvements within one year of civil acceptance of
development, the developer shall provide the City a cash escrow in
an amount equal to 100% of the value of constructing items not
completed or not already escrowed.
C. OFF SITE DRAINAGE IMPROVEMENTS
The developer will construct downstream drainage improvements by the
installation of 2 — 6' x 3' and 1 — 5' x 3' box culverts under Union Church
Road and grading the immediate downstream channel to Edgebrook Drive
in Keller. The City of Southlake will participate in the engineering,
construction and surveying of these improvements by reimbursing the
developer to the extent of 29.5% of actual costs not to exceed $59,306.00
upon final acceptance of construction and when funds are available.
D. TREE PRESERVATION ORDINANCE
All construction activities shall comply with the current Tree Preservation
Ordinance requirements and as may be amended by the City Council.
Page 10 of 18
Such conditions include, but are not limited to, proper posting of tree
protection warning signs and tree protective fencing to be maintained
throughout the duration of the project.
Page 11 of 18
SIGNED AND EFFECTIVE on the date last set forth below.
DEVELOPER
By:
Title:
Address:
STATE OF
COUNTY OF
On , before me, , Notary
Public, personally appeared
, personally known to me
(or proved to me on the basis of satisfactory evidence) to be the person whose name is
subscribed to the within instrument and acknowledged to me that he executed the same
in his authorized capacity, and that by his signature on the instrument, the person, or
the entity upon behalf of which the person acted, executed the instrument.
WITNESS my hand and official seal.
Notary Public
My commission expires:
(SEAL)
Page 12 of 18
CITY OF SOUTHLAKE, TEXAS
la
Andy Wambsganss, Mayor
ATTEST:
Lori Payne, City Secretary
Date:
Page 13 of 18
REQUIREMENTS FOR IRREVOCABLE LETTER OF CREDIT
1. The Letter of Credit must have duration of at least one year.
2. The Letter of Credit may be substituted for utility security deposits exceeding
$10,000.00. The City reserves the right to specify the face amount of the letter of
credit.
3. The Letter of Credit must be issued by a FDIC insured bank in a form acceptable
to the City of Southlake. The City reserves the right to approve /disapprove the
bank issuing the Letter of Credit.
4. The Letter of Credit must be issued by a bank that has a minimum capital ratio of
six (6 %) percent, and has been profitable for each of the last two consecutive
years.
5. The customer must provide the City with supporting financial information on the
bank to allow the City to ascertain requirements are met. Suitable financial
information would be the previous two (2) years December 31 Call Reports
submitted to the FDIC and audited financial statements.
6. Partial drawings against Letters of Credit must be permitted.
7. The City must be able to draft on sight with proof of amount owed.
8. The customer pays any and all fees associated with obtaining Letter of Credit.
9. Expiring Letter of Credit must be replaced by substitute Letters of Credit at least
30 days prior to the expiration date on the Letter of Credit held by the City.
Page 14 of 18
REQUIREMENTS FOR CONTRACTOR'S INSURANCE
Contractor's Insurance
1. Without limiting any of the other obligations or liabilities of the CONTRACTOR, during the term of
the Contract, the CONTRACTOR shall purchase and maintain the following minimum insurance
coverages with companies duly approved to do business in the State of Texas and satisfactory to the
CITY. In this section "Project" shall mean the public facilities to be constructed by Developer or under
Developer's contract with a CONTRACTOR. Coverages shall be of the following types and not less than
the specified amounts:
Workers' compensation as required by Texas law, with the policy endorsed to provide a
waiver of subrogation as to the CITY; employer's liability insurance of not less than the
minimum statutory amounts.
Commercial general liability insurance, including premises- operations; independent
CONTRACTOR's liability, completed operations and contractual liability covering, but not
limited to, the liability assumed under the indemnification provisions of this Contract, fully
insuring CONTRACTOR's (or Subcontractor's) liability for injury to or death of CITY's
employees and third parties, extended to include personal injury liability coverage with
damage to property of third parties, broad form property damage, with minimum limits as
set forth below:
General Aggregate . .....................$2,000,000
Bodily Injury $1,000,000 Each Occurrence
Property Damage $1,000,000 Each Occurrence
Products — Components /Operations Aggregate . $1,000,000
Personal and Advertising Injury ............ $ 1,000,000
(With Employment Exclusion deleted)
Each Occurrence ...................... $ 1,000,000
Contractual Liability:
Bodily Injury $1,000,000 Each occurrence
Property Damage $1,000,000 Each occurrence
The policy shall include coverage extended to apply to completed operations, asbestos
hazards (if this project involves work with asbestos) and ECU (explosion, collapse and
underground) hazards. The completed operations coverage must be maintained for a
minimum of one year after final completion and acceptance of the work, with evidence of
same filed with CITY.
C. Comprehensive automobile and truck liability insurance, covering owned, hired and non -
owned vehicles, with a combined bodily injury and property damage minimum limit of
$1,000,000 per occurrence; or separate limits of $500,000 for bodily injury (per person),
and $500,000 for property damage. Such insurance shall include coverage for loading
and unloading hazards.
d. Property Insurance (Builder's All Risk)
(i) CONTRACTOR shall purchase and maintain, at all times during the term of its
Contract with the Developer property insurance written on a builder's risk "all -
risk" or equivalent policy form in the amount of the initial contract price, plus
value of subsequent contract modifications and cost of materials supplied or
installed by others, comprising total value for the entire Project at the site on a
Page 15 of 18
replacement cost basis without optional deductibles. Such property insurance
shall be maintained, unless otherwise in writing by all persons and entities who
are beneficiaries of such insurance, until final payment has been made or until no
person or entity other than the CITY has an insurable interest in the property
required by this paragraph to be covered, whichever is later. This insurance shall
include interests of the CITY, the CONTRACTOR, Subcontractors and Sub -
Subcontractors in the Project.
(ii) Property insurance shall be on an "all- risk" or equivalent policy form and shall
include, without limitation, insurance against the perils of fire (with extended
coverage) and physical loss or damage including, without duplication of
coverage, theft, vandalism, malicious mischief, collapse, earthquake, flood,
windstorm, falsework, testing and startup, temporary buildings and debris
removal including demolition occasioned by enforcement of any applicable legal
requirements, and shall cover reasonable compensation for CONTRACTOR's
services and expenses required as a result of such insured loss.
(iii) If the insurance required by this paragraph requires deductibles, the
CONTRACTOR shall pay costs not covered because of such deductibles.
(iv) This property insurance shall cover portions of the Work stored off the site, and
also portions of the Work in transit.
d. OWNER's Protective Liability Insurance:
(i) CONTRACTOR shall obtain, pay for and maintain at all times during the
prosecution of the work under the contract between the CONTRACTOR and the
Developer, a CITY's protective liability insurance policy naming the CITY as
insured for property damage and bodily injury, which may arise in the prosecution
of the work or CONTRACTOR's operations under the contract.
Coverage shall be on an "occurrence" basis, and the policy shall be issued by the
same insurance company that carries the CONTRACTOR's liability insurance
with a combined bodily injury and property damage minimum limit of $1,000,000
per occurrence.
"Umbrella" Liability Insurance:
The CONTRACTOR shall obtain, pay for and maintain umbrella liability insurance during
the term of the Contract between the CONTRACTOR and the Developer, insuring
CONTRACTOR for an amount of not less than $5,000,000 per occurrence combined
limit for bodily injury and property damage that follows form and applies in excess of the
primary liability coverages required herein above. The policy shall provide "drop down"
coverage where underlying primary insurance coverage limits are insufficient or
exhausted.
Page 16 of 18
Policy Endorsements
Each insurance policy to be furnished by CONTRACTOR shall include the following
conditions by endorsement to the policy:
a. name the CITY as an additional insured as to all applicable policies;
b. each policy shall require that 30 days prior to cancellation, non - renewal or any
material change in coverage, a notice thereof shall be given to CITY by certified
mail. If the policy is canceled for nonpayment of premium, only 10 days written
notice to CITY is required;
C. the term "CITY" shall include all authorities, boards, bureaus, commissions,
divisions, departments and offices of the CITY and individual members,
employees and agents thereof in their official capacities, and /or while acting on
behalf of the CITY;
d. the policy- phrase "other insurance" shall not apply to the CITY where the CITY is an
additional insured on the policy.
2. Special Conditions
a. Insurance furnished by the CONTRACTOR shall be in accordance with the following
requirements:
any policy submitted shall not be subject to limitations, conditions or restrictions
deemed inconsistent with the intent of the insurance requirements to be fulfilled
by CONTRACTOR. The CITY's decision thereon shall be final;
ii. all policies are to be written through companies duly licensed to transact that
class of insurance in the State of Texas; and
iii. all liability policies required herein shall be written with an "occurrence" basis
coverage trigger.
b. CONTRACTOR agrees to the following:
i. CONTRACTOR hereby waives subrogation rights for loss or damage to the extent same
are covered by insurance. Insurers shall have no right of recovery or subrogation against
the CITY, it being the intention that the insurance policies shall protect all parties to the
contract and be primary coverage for all losses covered by the policies;
ii. companies issuing the insurance policies and CONTRACTOR shall have no
recourse against the CITY for payment of any premiums or assessments for any
deductibles, as all such premiums and deductibles are the sole responsibility and
risk of the CONTRACTOR;
iii. approval, disapproval or failure to act by the CITY regarding any insurance
supplied by the CONTRACTOR (or any Subcontractors) shall not relieve the
CONTRACTOR of full responsibility or liability for damages and accidents as set
forth in the Contract Documents or this Agreement. Neither shall be bankruptcy,
insolvency or denial of liability by the insurance company exonerate the
CONTRACTOR from liability;
Page 17 of 18
IN
u
deductible limits on insurance policies exceeding $10,000 require approval of the
CITY;
any of such insurance policies required under this paragraph may be written in
combination with any of the others, where legally permitted, but none of the
specified limits may be lowered thereby;
vii. prior to commencement of operations pursuant to this Contract, the Developer or
the Developer's CONTRACTOR shall furnish the CITY with satisfactory proof
that he has provided adequate insurance coverage in amounts and by approved
carriers as required by this Agreement;
viii. CONTRACTOR shall provide notice of any actual or potential claim or litigation
that would affect required insurance coverages to the CITY in a timely manner;
ix. CONTRACTOR agrees to either require its Subcontractors to maintain the same
insurance coverage and limits as specified for the CONTRACTOR or coverage of
Subcontractors shall be provided by the Contract; and
X. Prior to the effective date of cancellation, CONTRACTOR shall deliver to the
CITY a replacement certificate of insurance or proof of reinstatement.
Page 18 of 18
•
LU
o D
wa
I
I
3 u
Lu W W
--
I I
� I .
I
I
w cn
z w
C/)
� - - - -J
c
U U U U
J J J J
m m m m
D a a a
J J LL J J
I
O O O O
M CR W O
T- CO M 04
I I
f
t I
� III II
- -_ -- _
_ *
• 4i
yF
' II
ir
I
•
1 I
(w� �L� - L
y
I
II I
CU
I �
1
qy
9
III
I
I
i
�
I I
I I
I
J
1
tr.r4 J•1..rr
13
I
I
cu
w
I
/
i
r
I 1
I
I
F
I ry.
p
y Yu
I
•
N
t
ry itJ
�.
®
I L
1
P
�
y 4t
I
I
I
Lu W W
--
I I
;`;
w cn
z w
C/)
� - - - -J
c
U U U U
J J J J
m m m m
D a a a
J J LL J J
O O O O
M CR W O
T- CO M 04