Item 6A Draft Bylaws and CC&RsBYLAWS OF
MARANATHA RESIDENITAL HOMEOWNERS ASSOCIATION, INC.
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 1 of 20
ARTICLE 1
DEFINITIONS
1.1. Declaration. “Declaration” means the Declaration of Covenants, Conditions, and
Restrictions for the Maranatha Residential dated May **, 2019, and filed for record
(instrument #********) in the Official Public Records of Tarrant County, Texas, including any
amendments that may be made from time to time in accordance with its terms.
1.2. Manager. “Manager” means any professional manager or management company with
whom the Association contracts for the day-to-day management of the Subdivision or the
administration of the Association.
1.3. Subdivision. “Subdivision” means Maranatha Residential, Lots **, Block **, a
subdivision in Tarrant County, Texas, according to the Plats, including the land, all
improvements and structures on the land, and all easements, rights, and appurtenances to the
land, as more particularly described in the Declaration.
1.4. Other Terms. Other defined terms used in these Bylaws have the meaning given to
them in the Declaration, which is incorporated by reference and made a part of these Bylaws.
ARTICLE 2
APPLICABILITY OF BYLAWS
2.1. Corporation. The provisions of these Bylaws constitute the Bylaws of Maranatha
Residential Homeowners Association, Inc., a Texas nonprofit corporation (“Association”).
2.2. Applicability. The provisions of these Bylaws are applicable to the Subdivision as
defined above.
2.3. Personal Application. All present or future Owners, present or future tenants, their
employees, or other Persons that use the facilities of the Su bdivision in any manner are subject
to the regulations set forth in these Bylaws. The acquisition or rental of any of the Lots of the
Subdivision, or the act of occupancy of any of the Lots, will signify that these Bylaws are
accepted and ratified and will be complied with by the purchaser, tenant, or occupant.
ARTICLE 3
OFFICES
3.1. Principal Office. The principal office of the Association will be located at *****,
Southlake TX 76092. The Board may change the location of the principal office from time to
time.
3.2. Registered Office and Registered Agent. The Association will have and will
continuously maintain in the State of Texas a registered office and a registered agent whose
office will be the same as the registered office, as required by the Texas Business
Organizations Code. The registered office may be, but need not be, the same as the principal
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 2 of 20
office of the corporation. The Board may change the address of the registered office from time
to time.
ARTICLE 4
QUALIFICATIONS FOR MEMBERSHIP
4.1. Membership. Every Owner of a Lot will automatically be a Member of the
Association. Membership will be appurtenant to and may not be separated from ownership of a
Lot. Each Member will be entitled to cast one (1) vote for each Lot owned with respect to any
matter on which members of the Association are entitled to vote. In cases where more than one
Person owns a fee interest in a Lot, all such Persons will arrange among themselves for one of
them to exercise the voting rights attributable to their Lot. Membership of a Member in the
Association will automatically terminate when the Member ceases to be an Owner. The
termination, however, will not release or relieve the Member from any liability or obligation
under the Restrictions that was incurred during the Member’s period of ownership of a Lot.
4.2. Proof of Member. The rights of membership will not be exercised by any Person until
satisfactory proof has been furnished to the Secretary of the Association that the Person is
qualified as a Member. This proof may consist of a copy of a duly executed and acknowledged
deed or title-insurance policy evidencing ownership of a Lot. A deed or policy will be deemed
conclusive in the absence of a conflicting claim based on a later deed or policy.
4.3. No Additional Qualifications. The sole qualification for membership will be the
ownership of a Lot. No initiation fees or dues will be assessed against any Person as a
condition of membership except the assessments, levies, and charges specifically authorized
under the Certificate of Formation or the Declaration.
4.4. Certificates of Membership. The Board may provide for the issuance of certificates
evidencing membership in the Association in such form as may be determined by the Board.
All certificates evidencing membership will be consecutively numbered. The name and address
of each Member and the date of issuance of the certificate will be entered on the records of the
Association and maintained by the Secretary of the Association at the registered office of the
Association.
ARTICLE 5
VOTING RIGHTS
5.1. Allocation. Voting rights will be allocated among the Members on the basis of the
formulas and allocations set forth in the Declaration. The Association will have two classes of
voting members as follows:
Class A: Class “A” Members will include each Owner (excluding Declarant) of a Lot
within the Property, and each Owner will have one (1) vote for each Lot owned. When
more than one person holds such interest or interests in any Lot, all such persons shall be
Members, and the vote for such Lot shall be exercised as they, among themselves,
determine, but in no event shall more than one (1) vote be cast with respect to any such
Lot.
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 3 of 20
Class B: Class “B” Member will be the Declarant, and Declarant will have thirteen (13)
votes for each Lot it owns. The Class B Membership will convert to a Class A
Membership when (a) Declarant has conveyed all Lots to owners or (b) Declarant
voluntarily converts the Class B Membership to a Class A Membership by written
instrument recorded in the Real Property/Official/Deed Records of Tarrant County, Texas,
whichever occurs first.
5.2. Manner of Voting. At all meetings of Members, each Member, subject to Section 4.1,
may vote in person, by a legitimate proxy in form approved by the Board, by absentee ballot,
or by electronic ballot. All proxies must be in writing and filed with the Secretary of the
Association before any Member may vote by proxy. Every proxy will be revocable and will
automatically cease on conveyance by the Member of the Member’s Lot or on receipt of notice
by the Secretary of the Association of the death or judicially declared incompetence of the
Member. No proxy will be valid after eleven (11) months from the date of its execution, unless
otherwise specifically provided in the proxy.
5.3. Quorum. Except as otherwise specifically provided in the Declaration or the
Certificate of Formation, the presence, either in person, by proxy, by absentee ballot, or by
electronic ballot, at any meeting of Members entitled to cast at least fifty-one percent (51%) of
the total voting power of the Association will constitute a quorum for any action; however, an
absentee or electronic ballot may be counted as a Member present and voting for the purpose
of establishing a quorum only for items appearing on the ballot. In the absence of a quorum at a
meeting of Members, a majority of those Members present in person or by proxy may adjourn
the meeting to a time no less than five (5) days or more than thirty (30) days from the meeting
date.
5.4. Required Vote. The vote of the majority of the votes entitled to be cast by the
Members present, or represented by proxy, by absentee ballot, or by electronic ballot, at a
meeting at which a quorum is present will be the act of the Members, unless the vote of a
greater number is required by statute, the Declaration, or the Certificate of Formation;
however, an absentee or electronic ballot may not be counted, even if properly delivered, if the
Member actually attends the meeting to vote in person and does so cast a vote at the meeting,
and may not be counted on the final vote of a proposal if the motion was amended at the
meeting to be different from the exact language on the absentee or electronic ballot.
5.5. Absentee Ballots. A solicitation for votes by absentee ballot must include (a) an
absentee ballot that contains each proposed action and provides an opportunity to vote for or
against each proposed action, (b) instructions for delivery of the completed absentee ballot,
including the delivery location, and (c) the following language: “By casting your vote via
absentee ballot you will forgo the opportunity to consider and vote on any action from the floor
on these proposals, if a meeting is held. This means that if there are amendments to these
proposals your votes will not be counted on the final vote on these measures. If you want to
retain this ability, please attend any meeting in person. You may submit an absentee ballot and
later choose to attend any meeting in person, in which case any in-person vote will prevail.”
5.6. Electronic Ballots. An electronic ballot means a ballot (a) given by electronic mail,
fax, or posting on an Internet website, (b) for which the identity of the Member submitting the
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 4 of 20
ballot can be confirmed, and (c) for which the Member may receive a receipt of the electronic
transmission and receipt of the Member’s ballot. If an electronic ballot is posted on an Internet
website, a notice of the posting will be sent to each Member with instructions on obtaining
access to the posting on the website.
ARTICLE 6
MEETINGS OF MEMBERS
6.1. Annual Meeting. The first meeting of the Members of the Association will be held
within one hundred twenty (120) days after the closing of the sale of fifty percent (50%) of the
Lots to Owners other than Declarant or within six (6) months after the closing of the sale of the
first Lot within the Subdivision, whichever is earlier. After the first meeting, the annual
meeting of the Members of the Association will be held on the second Tuesday of April of
each succeeding calendar year at the hour of 7:00 p.m. unless otherwise determined by the
Board. If the day for the annual meeting of the Members is a legal holiday, the meeting will be
held at the same hour on the first day following that is not a legal holiday.
6.2. Special Meeting. Special meetings of the Members may be called by the President of
the Association, by the Board, or by Members representing at least twenty percent (20%) of the
total voting power of the Association unless otherwise required by law.
6.3. Place. Meetings of the Members will be held within the Subdivision or at a meeting
place as close to the Subdivision as possible, as permitted by law and spec ified by the Board in
writing.
6.4. Notice of Meetings. Written notice of all Members’ meetings will be given by or at the
direction of the Secretary of the Association or such other Persons as may be authorized to call
the meeting, by mailing or personally delivering a copy of the notice at least ten (10) but no
more than sixty (60) days before the meeting to each Member entitled to vote at the meeting.
The notice must be addressed to the Member’s address last appearing on the books of the
Association or supplied by the Member to the Association for the purpose of notice. The notice
must specify the place, day, and hour of the meeting and, in the case of a special meeting, the
nature of the business to be undertaken.
6.5. Order of Business. The order of business at all meetings of the Members will be as
follows:
(a) Roll call.
(b) Proof of notice of meetings or waiver of notice.
(c) Reading of minutes of preceding meeting.
(d) Election of directors.
(e) Reports of officers.
(f) Reports of committees.
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 5 of 20
(g) Unfinished business.
(h) New business.
6.6. Action Without Meeting. Any action that must or may be taken at a meeting of the
Members, other than the election of Directors, may be taken without a meeting if a consent in
writing, setting forth the action to be taken, is signed by the requisite number or voting power
of the Members and filed with the Secretary of the Association. A Member can consent to an
action to be taken by electronic mail (e-mail). Consent by e-mail is considered to be written,
signed, and dated for the purposes of this Section if the e-mail sets forth or is delivered with
information from which the Association can determine that the e-mail was transmitted by the
Member and the date on which the Member transmitted the e-mail. The date of the e-mail is
the date on which the consent was signed. Consent given by e-mail may not be considered
delivered until the consent is reproduced in paper form and the paper form is delivered to the
Association at its registered office in this state or its principal place of business, or to an officer
or agent of the Association having custody of the book in which proceedings of Member
meetings are recorded. Consent given by e-mail may be delivered to the principal place of
business of the Association or to an Officer or agent of the Association having custody of the
book in which proceedings of Member meetings are recorded to the extent and in the manner
provided by these Bylaws. Any photographic, fax, or similarly reliable reproduction of a
consent in writing signed by a Member may be substituted or used instead of the original
writing for any purpose for which the original writing could be used, if the reproduction is a
complete reproduction of the entire original writing.
ARTICLE 7
BOARD OF DIRECTORS
7.1. Governing Body; Composition. The Board of Directors “Board” will govern the
affairs of the Association. Each Director will have one equal vote. In the case of a Member that
is not a natural Person, any officer, director, partner, member, manager, employee, or fiduciary,
agent, or appointed representative of the Member will be eligible to serve as a Director unless
otherwise specified by written notice to the Association signed by the Member, provided that
no Member may have more than one representative on the Board at a time. However, if a
member owns multiple lots then a member may have one representative for every lot owned.
7.2. Number. The number of Directors of the Association shall be three (3). The number of
Directors may be increased or decreased from time to time by an amendment to these Bylaws
or resolution adopted by the Board of Directors, provided that the number of directors may not
be decreased to fewer than three (3). No later than upon the City of Southlake issuing the third
(3rd) certificate of occupancy within Maranatha Residential, a resident (who resides in the
subdivision) shall be appointed to the Board. The number of Directors authorized will be fixed
as the Board may from time to time designate, or if no designation has been made, the number
of Directors will be the same as the number of members of the initial Board as set forth in the
Certificate of Formation. No decrease in the number of Directors will have the effect of
shortening the term of any incumbent Director.
7.3. Term. The initial Directors are those Persons identified in the Certificate of Formation.
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 6 of 20
Except as otherwise set forth in these Bylaws and in the Declaration, each Director will serve a
term of one (1) year and may serve an unlimited number of consecutive terms. At the first
annual meeting of members and at each annual meeting thereafter, the members shall elect
directors. A director shall hold office until the next annual election of directors and until said
director’s succors shall have been elected, appointed, or designated and qualified.
7.4. Removal. Directors may be removed, with or without cause, by the Members at a
special meeting of the Members duly called for that purpose. Notice of the meeting must be
given to all Directors. If the Board is presented with written, documented evidence from a
database or other record maintained by a law enforcement authorit y that a Director has been
convicted of a felony or crime involving moral turpitude, the Director is immediately ineligible
to serve on the Board, automatically considered removed from the Board, and prohibited fro m
future service on the Board.
7.5. Vacancies. If the office of any Director becomes vacant for any reason, the remaining
Directors will choose a successor to fill the unexpired term of the directorship being vacated at
a special meeting called for that purpose. At the expiration of the term of his or her position on
the Board, any successor Director chosen by the remaining Directors or by the Members will
be re-elected or his or her successor will be elected in accordance with these Bylaws. Any
directorship to be filled by reason of an increase in the number of Directors will be filled by
election at an annual meeting of Members or at a special meeting of Me mbers called for that
purpose.
7.6. Compensation. No Director will receive compensation for any services rendered to the
Association. A Director may be reimbursed by the Board for actual expenses incurred by the
Director in the performance of the Director’s duties.
7.7. Powers and Duties. The Board will have the powers and duties of a Texas nonprofit
corporation and will be subject to the limitations on these powers and duties, as enumerated in
the Declaration. The Board will further have the power to do and perform any and all acts that
may be necessary or proper for or incidental to the exercise of any of the express powers
granted to it by the laws of Texas. Without in any way limiting the generality of the two
preceding sentences, the Board, acting on behalf of the Association, will have the following
powers and authority:
(a) Rules and Bylaws. To make, establish, promulgate, amend, repeal, and re-enact the
Association Rules and Bylaws. The Board may establish the content of the Association Rules
and Bylaws, provided that they do not conflict with this Declaration.
(b) Insurance. To obtain and maintain in effect policies of insurance that, in the
opinion of the Board, are reasonably necessary or appropriate to carry out the Association’s
functions.
(c) Records. To keep books and records, including financial records, of the
Association’s affairs.
(d) Assessments. To levy Assessments as provided in Article 8 of the Declaration. An
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 7 of 20
Assessment is defined as the amount that must be levied in the manner and against the
property set forth in Article 8 of the Declaration in order to raise the total amount for which
the levy in question is being made.
(e) Right of Entry and Enforcement. To only enter an Owners lot after twenty-four
(24) hours written notice, without being liable to any Owner, for the purpose of enforcing the
Restrictions or for the purpose of maintaining or repairing any area, Improvement, or other
facility to conform to the Restrictions, and the expense incurred by the Association in
connection with the entry on any Lot and the maintenance and repair work conducted on it
will be a personal obligation of the Owner of the Lot entered on, will be a lien on the Lot
entered on and the Improvements on the Lot, and will be enforced in the same manner and to
the same extent as provided in Article 8 for regular Assessments. The Association will have
the power and authority from time to time, in its own name and on its own behalf, or in the
name of and on behalf of any Owner who consents to it, to commence and maintain actions
and suits to enforce, by mandatory injunction or otherwise, or to restrain and enjoin, any
breach or threatened breach of the Restrictions. The Association is also authorized to settle
claims, enforce liens, and take all action as it may deem necessary or expedient to enforce the
Restrictions; however, the Board will never be authorized to expend any Association funds
for the purpose of bringing suit against Declarant, any Builder, and any of their respective
successors and assigns.
(f) Legal and Accounting Services. To retain and pay for legal and accounting
services necessary or proper in the operation of the Association.
(g) To enter into contracts, maintain one or more bank accounts, and generally, to
have all the powers necessary or incidental to the operation and management of the
Association
(h) To make available to each Owner within ninety (90) days after the end of each
year an annual report.
(i) To accept, own, operate, and maintain all Common Area and Facilities that may be
conveyed or leased to it by Declarant, together with all Improvements of any kind and for
any purpose that may be located in those areas, and to accept, own, operate, and maintain all
other property, real or personal, conveyed or leased to the Association by Declarant and to
maintain in good repair and condition all lands, improvements, and other Association
property owned by or leased to the Association. Such maintenance will include, but will not
be limited to, painting, mowing, and removing rubbish or debris of any kind.
(j) To pay all real-property taxes, personal-property taxes, and other taxes and
Assessments levied on or with respect to Common Area and Facilities or any other property
owned by or leased to the Association to the extent that the taxes and Assessments are not
levied directly on the Members of the Association. The Association will have all rights
granted by law to contest the legality of the amount of the taxes and Assessments.
(k) To take out and maintain current a policy of liability-insurance coverage to cover
accidental bodily injury or death caused by the use and enjoyment of the Common Area and
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 8 of 20
Facilities. This insurance will be in an amount, as the Board deems appropriate.
(l) To borrow funds to pay costs of operation, secured by assignment or pledge of rights
against delinquent Owners, if the Board sees fit or with prior written consent of two-thirds
(2/3’s) of each class of Members secured by such assets of the Association as deemed
appropriate by the lender and the Association.
(m) The right to dedicate or transfer all or any part of the Common Properties to any
municipal corporation, public agency, authority or utility company for such purposes and
upon such conditions as may be agreed upon by Declarant and the Members having a
majority of the outstanding eligible votes of the Association.
(n) The right to convey, sell or lease all or part of the Common Properties upon such
terms and conditions as may be agreed upon by Declarant and the members having a
majority of the outstanding eligible votes of the Association.
(o) The right to enter into and execute contracts with the owner-operators of any
community antenna television system or other similar operations such as telephones, or
telecommunications for the purpose of extending cable, telephone, computer or
telecommunications equipment or utility service on, over or under the Common Properties
ultimately provide service to one or more of the Lots.
(p) Supervise all officers, agents, and employees of the association and see to it that
their duties are properly performed
(q) To file assessment liens and foreclosure on assessment liens under the rules adopted
by the Texas Supreme Court.
7.8. Nomination and Election of Directors.
(a) Nomination. Nomination for election to the Board will be made from the floor
at the annual meeting of the Members, or the Members may appoint a nomination committee
before the annual meeting of the Members for the purpose of soliciting Members to serve as
a member of the Board and presenting to the Members before the annual meeting a list of all
the interested Members.
(b) Election. Directors are elected at the annual meeting of Members. Members or
their proxies may cast, in respect to each vacant directorship, as many votes as they are
entitled to exercise under the provisions of the Declaration. The nominees receiving the
highest number of votes will be elected. Cumulative voting is prohibited.
7.9. Standard of Care. Except as otherwise provided in the Declaration, elsewhere in these
Bylaws, the Board will act in all instances on behalf of the Association if in the good-faith
judgment of the Board the action is reasonable. Each member of the Board is liable as a
fiduciary of the Owners for the Board member’s acts or omissions.
7.10. Manager. If the Board determines that it is in the Association's best interest to hire a
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 9 of 20
Manager for the Subdivision to facilitate management of the Subdivision or the administration
of the Association, the Board may delegate to a Manager responsibility for matters of a routine
nature, renewable by agreement of the parties for successive one-year (1-year) periods only.
The Manager will be subject to termination by either party with or without cause and without
payment of a termination fee on no more than thirty (30) days written notice. After a Manager
has been appointed, no decision by the Association to manage its own affairs without a
Manager will be effective unless and until approved by Members holding at least fifty-one
percent (51%) of the votes at the meeting called to consider the matter with the written consent
of at least fifty-one percent (51%) of the Mortgagees.
ARTICLE 8
OFFICERS
8.1. Enumeration of Officers. The Officers of the Association will be a President, a Vice
President, a Secretary, and a Treasurer. The Board may, by resolution, create any other offices
it deems necessary or desirable.
8.2. Term. The Officers of the Association will be elected annually by the Board and each
will hold office for one (1) year, unless the Officer resigns, is removed, or is otherwise
disqualified to serve, and until his successor is elected and qualified.
8.3. Resignation; Removal. Any Officer may resign at any time by giving written notice to
the Board. A resignation will take effect on the date notice is received or at any later time
specified in the notice. Any Officer may be removed from office by the Board whenever, in the
Board’s judgment, the Association's best interests would be served by the removal, except that
the Board will have no authority to remove, and cannot remove, any Officer elected by
Declarant.
8.4. Multiple Offices. The same Person may simultaneously hold any two or more offices,
except that the same Person may not simultaneously hold the offices of President and
Secretary.
8.5. Compensation. No Officer will receive compensation for any services rendered to the
Association. An Officer may be reimbursed by the Board for actual expenses incurred by the
Officer in the performance of the Officers duties.
8.6. Duties, Obligations, and Authority of the Officers.
(a) President. The President of the Association will perform the following duties:
(1) Preside over all meetings of the Members and of the Board.
(2) Sign as President all deeds, contracts, and other instruments in writing
that have been first approved by the Board, unless the Board, by duly adopted resolution, has
additionally authorized the signature of another Officer.
(3) Call meetings of the Board whenever he deems it necessary in
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 10 of 20
accordance with the Association Rules and on notice as required by the Declaration.
(4) Have, subject to the advice of the Board, general supervision, direction,
and control of the affairs of the Association and discharge any other duties as may be
required of him by the Board.
(5) Prepare, execute, certify, and have recorded all amendments to the
Declaration made by the Association.
(b) Vice President. The Vice President of the Association will perform the
following duties:
(1) Act in the place of the President in the event of the President’s absence,
inability, or refusal to act.
(2) Exercise and discharge any other duties as may be required of the Vice
President by the Board, and in connection with any additional duties, the Vice President will
be responsible to the President.
(c) Secretary. The Secretary of the Association will perform the following duties:
(1) Keep a record of all meetings and proceedings of the Board and of the
Members.
(2) Keep the seal of the Association and affix it on all papers requiring the
seal.
(3) Serve notices of meetings of the Board and the Members required either
by law or by these Bylaws.
(4) Keep appropriate current records showing the Members together with
their addresses.
(5) Sign as Secretary all deeds, contracts, and other instruments in writing
that have been first approved by the Board if the instruments require a second signature by
the Association, unless the Board has authorized another Officer to sign in the place and
stead of the Secretary by duly adopted resolution.
(6) Prepare, execute, certify, and have recorded all amendments to the
Declaration required by statute to be recorded by the Association.
(d) Treasurer. The Treasurer of the Association will perform the following duties:
(1) Receive and deposit in a bank or banks, as the Board may from time to
time direct, all of the funds of the Association.
(2) Be responsible for and supervise the maintenance of books and records
to account for the Association’s funds and other Association assets.
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 11 of 20
(3) Disburse and withdraw funds as the Board may from time to time direct
and in accordance with prescribed procedures.
(4) Prepare and distribute the financial statements for the Association
required by the Declaration.
8.7. Qualification. Only Members will be qualified to serve as Officers of the Association,
except for the office of Secretary, which need not be held by a Member.
8.8. Standard of Care. Except as otherwise provided in the Certificate of Formation, these
Bylaws, or the Declaration, each Officer is liable as a fiduciary of the Owners for the Officer’s
acts or omissions.
ARTICLE 9
NO PERSONAL LIABILITY; INDEMNIFICATION
9.1. No Personal Liability. To the fullest extent permitted by applicable law, a Director or
Officer will not be liable to the Association or its Members for monetary damages for any act
or omission in the Director’s or Officer’s capacity as such, except that this Section does not
eliminate or limit the liability of a Director or Officer to the extent the Director or Officer is
found liable for any of the following:
(a) A breach of the Director’s or Officer’s duty of loyalty to the Association or its
Owners.
(b) An act or omission not in good faith that constitutes a breach of duty of the
Director or Officer to the Association or an act or omission that involves intentional
misconduct or a knowing violation of the law.
(c) A transaction from which the Director or Officer received an improper b enefit,
whether or not the benefit resulted from an action taken within the scope of the Director’s or
Officer’s office.
(d) An act or omission for which the liability of a Director or Officer is expressly
provided by an applicable statute.
Any repeal or amendment of this Section by the Members of the Association will be
prospective only and will not adversely affect any limitation on the personal liability of a
Director or Officer arising from an act or omission occurring before the time of the repeal o r
amendment. In addition to the circumstances in which a Director or Officer is not personally
liable as set forth in the foregoing provisions of this Section, a Director or Officer will not be
liable to the Association or its Members to the extent as permitted by any law enacted after
these Bylaws, including, but not limited to, any subsequent amendment to the Texas
Business Organizations Code.
9.2. Indemnification. The Association will indemnify any Person who was, is, or is
threatened to be made a named defendant or respondent in a proceeding (as defined in
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 12 of 20
Section 9.5) because the Person (a) is or was a Director or Officer of the Association or
(b) while a Director or Officer of the Association, is or was serving at the request of the
Association as a director, officer, partner, venture, proprietor, trustee, employee, agent,
or similar functionary of another foreign or domestic corporation, partnership, joint
venture, sole proprietorship, trust, employee-benefit plan, or other enterprise, to the
fullest extent that a corporation may grant indemnification to a Director or Officer under
the Texas Business Organizations Code, as it exists or may later be amended. This right
will be a contract right that will run to the benefit of any Director or Officer who is
elected and accepts the position of Director or Officer of the Association or elects to
continue to serve as a Director or Officer of the Association while this Section is in effect.
Any repeal or amendment of this Section will be prospective only and wi ll not limit the
rights of any Director or Officer or the obligations of the Association with respect to any
claim arising from or related to the services of a Director or Officer in any of the
foregoing capacities before any repeal or amendment of this Section. This right will
include the right to be paid or reimbursed by the Association for expenses incurred in
defending any proceeding in advance of its final disposition to the maximum extent
permitted under the Texas Business Organizations Code, as it exists or may later be
amended. If a claim for indemnification or an advancement of costs of defense under
these Bylaws is not paid in full by the Association within ninety (90) days after a written
claim has been received by the Association, the claimant may bring suit against the
Association to recover the unpaid amount of the claim, and if successful in whole or in
part, the claimant will also be entitled to be paid the expenses of prosecuting the claim. It
will be a defense to any action that the indemnification or advancement of costs of defense
is not permitted under the Texas Business Organizations Code, but the burden of proving
this defense will be on the Association. Neither the failure of the Association (including
the Board or any committee of the Board, special legal counsel, or Members) to have
made its determination before the commencement of an action nor an actual
determination by the Association (including the Board or any committee of the Board,
special legal counsel, or Members) that the indemnification or advancement is not
permissible will be a defense to the action or create a presumption that the
indemnification or advancement is not permissible. If any Person having a right of
indemnification under the foregoing provisions dies, the righ t will inure to the benefit of
his or her heirs, executors, administrators, and personal representatives.
9.3. Rights Not Exclusive. The rights conferred in Section 9.2 are not exclusive of any
other right that any Person may have or later acquire under an y statute, these Bylaws, the
Certificate of Formation, any resolution of Owners or Directors, by agreement, or otherwise.
9.4. Mandatory Indemnification. THE ASSOCIATION MAY ADDITIONALLY
INDEMNIFY ANY PERSON COVERED BY THE GRANT OF MANDATORY
INDEMNIFICATION TO SUCH FURTHER EXTENT AS IS PERMITTED BY LAW AND
MAY INDEMNIFY ANY OTHER PERSON TO THE FULLEST EXTENT PERMITTED BY
LAW. TO THE EXTENT PERMITTED BY THEN APPLICABLE LAW, THE GRANT OF
MANDATORY INDEMNIFICATION TO ANY PERSON UNDER THIS ARTICLE WILL
EXTEND TO PROCEEDINGS INVOLVING THE NEGLIGENCE OF THE PERSON.
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 13 of 20
9.5. Definition of Proceeding. As used in these Bylaws, the term “proceeding” means any
threatened, pending, or completed action, suit, or proceeding (whether civil, criminal,
administrative, arbitrative, or investigative); any related appeal; and any inquiry or
investigation that could lead to such an action, suit, or proceeding.
9.6. Other. Contracts or other commitments made by the Board, the Officers, or the
Manager will be made by these Persons as agents for the Owners, and the Board, the Officers,
and the Manager will have no personal responsibility on any contract or commitment (except
as Owners), and the liability of any Owner on a contract or commitment will be limited to the
proportionate share of the total liability that each Owner shares with respect to Assessments.
ARTICLE 10
MEETINGS OF DIRECTORS
10.1. Regular Meetings. Regular meetings of the Board will be held quarterly at a place
within the Subdivision or at any other place permitted by law and designated at any time by
resolution of the Board, at a time as may be fixed from time to time by resolution of the Board.
Notice of the time and place of regular meetings will be posted at a prominent place within t he
Common Area and Facilities.
10.2. Special Meetings. Special meetings of the Board will be held when called by written
notice signed by the President of the Association or by any two (2) Directors at a place within
the Subdivision or at any other place permitted by law and designated at any time by resolution
of the Board. The notice will specify the time and place of the meeting and the nature of any
special business to be considered. Written notice of a special meeting must be given to each
Director not less than three (3) days or more than fifteen (15) days before the date fixed for the
meeting. The written notice must be delivered personally, sent by mail, or sent by fax to each
Director at the Director’s address as shown in the records of the Association. A copy of the
notice will be posted in a prominent place or places in the Common Area and Facilities of the
Subdivision at least three (3) days before the date of the meeting.
10.3. Quorum. A majority of the directors will constitute a quorum for the transaction of
business. Every act performed or decision made by a majority of directors present at a duly
held meeting in which a quorum is present will constitute the act or decision of the board.
10.4. Voting Requirement. The act of a majority of Directors present at a meeting at which a
quorum is present will be the act of the Board unless any provision of any of the Restrictions
requires the vote of a greater number.
10.5. Action Without Meeting. Any action involving routine or administrative matters or a
reasonably unforeseen emergency or urgent necessity that requires immediate action that may
be taken at a meeting of the Directors may be taken without a meeting if a consent in writing,
setting forth the action so taken, is signed by the requisite number or voting power of the
Directors and filed with the Secretary of the Association. A Director can consent to an action to
be taken by electronic mail (e-mail). Consent by e-mail is considered to be written, signed, and
dated for the purposes of this Section if the e-mail sets forth or is delivered with information
from which the Association can determine that the e-mail was transmitted by the Director and
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 14 of 20
the date on which the Director transmitted the e-mail. The date of the e-mail is the date on
which the consent was signed. Consent given by e-mail may not be considered delivered until
the consent is reproduced in paper form and the paper form is delivered to the Association at its
registered office in this state or its principal place of business, or to an officer or agent of the
Association having custody of the book in which proceedings of Director meetings are
recorded. Consent given by e-mail may be delivered to the principal place of business of the
Association or to an Officer or agent of the Association having custody of the book in which
proceedings of Director meetings are recorded to the extent and in the manner provided by
these Bylaws. Any photographic, fax, or similarly reliable reproduction of a consent in writing
signed by a Director may be substituted or used instead of the original writing for any purpose
for which the original writing could be used, if the reproduction is a complete reproduction of
the entire original writing.
10.6. Open Meetings. Regular and special meetings of the Board will be open to all Members
of the Association; however, Members who are not members of the Board may not participate
in any deliberation or discussion unless expressly authorized to do so by the vote of a majo rity
of a quorum of the Board.
10.7. Executive Session. The Board may, with the approval of a majority of a quorum, adjourn
a meeting and reconvene in executive session to discuss and vote on personnel matters,
litigation in which the Association is or may become involved, contract negotiations,
enforcement actions, confidential communications with the Association’s attorneys, matters
involving the invasion of privacy of individual Members, other business of a confidential
nature involving a Member, and matters requested by the involved parties to remain
confidential. The nature of any business to be considered in executive session will first be
announced in open session. Any decision made in the executive session must be summarized
orally and placed in the minutes, in general terms, without breaching the privacy of individual
owners, violating any privilege, or disclosing information that was to remain confidential at the
request of the affected parties. The oral summary must include a general explanation of
expenditures approved in the executive session.
10.8. Meeting Minutes. The Board will keep a record of each regular or special meeting of the
Board in the form of written minutes of the meeting. The Board will make meeting records,
including approved minutes, available to the Members for inspection and copying on written
request to the Manager at the address appearing on the most recently filed management
certificate, or if there is not a Manager, to the Board.
10.9. Notice to Members. Except for actions taken by the Board without a meeting under
Section 10.5 and meetings held by telephone conference or other similar remote or electronic
communication system in which all Persons participating in the meeting can hear each other,
Members will be given notice of the date, time, place, and general subject of all regular or
special meetings of the Board, including a general description of any matter to be brought up
for deliberation in executive session. The notice must be (1) mailed to each Member no earlier
than sixty (60) days and no later than ten (10) days before the meeting; o r (2) provided at least
seventy-two (72) hours before the start of the meeting by (a) posting the notice in a
conspicuous manner reasonably designed to provide notice to the Members (i) in a prominent
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 15 of 20
place or places in the Common Area and Facilities of the Subdivision or, with the consent of
the applicable Owner, on other conspicuously located privately owned property within the
Subdivision, or (ii) on any Internet website maintained by the Association or other Internet
media; and (b) sending the notice by electronic mail (e-mail) to each Member who has
registered an e-mail address with the Association. Each Member must keep an updated e-mail
address registered with the Association. If the Board recesses a regular or special meeting of
the Board to continue the following regular business day, the Board is not required to post
notice of the continued meeting if the recess is taken in good faith and not to circumvent the
notice requirements of this Section. If a regular or special meeting of the Board is continued to
the following regular business day, and on that following day the Board continues the meeting
to another day, the Board will give notice of the continuation in at least one manner prescribed
by this Section within two (2) hours after adjourning the meeting being continued. Any action
taken without notice to the Members under this Section must be summarized orally, including
an explanation of any known actual or estimated expenditures approved at the applicable
regular or special meeting, and documented in the minutes of the next regular or special
meeting of the Board. Despite anything in these Bylaws to the contrary, the Board may not,
without prior notice to the Members under this Section, consider or vote on (1) fines,
(2) damage assessments, (3) initiation of foreclosure actions, (4) initiation of enforcement
actions, excluding temporary restraining orders or violations involving a threat to health or
safety, (5) increases in Assessments, (6) levying of special Assessments, (7) appeals from a
denial of Architectural Committee approval, or (8) a suspension of a right of a particular
Owner before the Owner has an opportunity to attend a meeting of the Board to present the
Owner’s position, including any defense, on the issue.
ARTICLE 11
BOOKS AND RECORDS
11.1. Maintenance. Complete and correct records of account and minutes of proceedings of
meetings of Members, Directors, and committees will be kept at the Association’s registered
office or principal office in the State of Texas. A record containing the names and addresses of
all Members entitled to vote will be kept at the Association’s registered office or principal
office in the State of Texas.
11.2. Inspection. The Restrictions and other items listed in Section 6.04(c) of the Declaration
will be available for inspection and copying by any Member or any Director for any proper
purpose upon the terms and conditions and subject to the requirements of Texas Property Code
section 209.005 (or any successor statute).
ARTICLE 12
GENERAL PROVISIONS
12.1. Amendment of Bylaws. These Bylaws may be amended, altered, or repealed at a regular
or special meeting of the Members by the affirmative vote in person or by proxy of Members
representing fifty-one percent (51%) of the Members; however, these Bylaws will not be
amended or otherwise changed or interpreted so as to be inconsistent with the Declaration.
Despite the preceding sentence, the percentage of affirmative votes necessary to amend a
specific clause or provision will not be less than the prescribed percentage of affirmative votes
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 16 of 20
required for action to be taken under that clause or provision. Further, the Members may not
meet to adopt an amendment or other change to these Bylaws unless the Association or Board
has given to each Owner a document showing the specific amendment or other change that
would be made to the Bylaws no earlier than sixty (60) days and no later than ten (10) days
before the date of the meeting. The information is considered to have been given to an Owner
on the date the information is personally delivered to the Owner, as shown by a receipt signed
by the Owner, or on the date shown by the postmark on the information after it is deposited in
the U.S. mail with a proper address and postage paid. If any proposed amendment to these
Bylaws would affect less than all of the Lots, the amendment will not be effective without the
consent of the Owners of those Lots adversely affected by the amendment.
12.2. Notices.
(a) Any notice, demand, or other communication required to be given or to be
served on any Person must be in writing and delivered to the Person to whom the notice is
directed (1) in person, (2) by U.S. mail, registered or certified, return receipt requested,
(3) by a nationally recognized overnight delivery service, or (4) by e-mail. Notices, demands,
or other communications delivered by mail will be deemed given and received when
deposited in a post office or other depository under the care or custody of the U.S. Postal
Service, enclosed in a wrapper, addressed properly, and with proper postage affixed. Any
notice, demand, or other communication given other than by certified or registered mail,
return receipt requested, will be deemed to have been given and received when delivered to
the Person at the Person’s current address as reflected in the records of the Secretary.
(b) On the consent of any Person, notice from the Association may be given to the
Person by electronic transmission. Any Person may specify the form of electronic
transmission to be used to communicate notice. The Person may revoke this consent by
written notice to the Association. The consent is deemed to be revoked if the Association is
unable to deliver by electronic transmission two (2) consecutive notices, and the Person
responsible for delivering notice on behalf of the Association knows that delivery of these
two (2) electronic transmissions were both unsuccessful. The inadvertent failure to treat the
unsuccessful transmissions as a revocation of consent does not invalidate a meeting or other
action. Notice b y electronic transmission is deemed given when the notice is (1) transmitted
to a fax number provided by the Person for the purpose of receiving notice, (2) transmitted to
an e-mail address provided by the Person for the purpose of receiving notice, (3) posted on
an electronic network and a message is sent to the Person at the address provided by the
Person for the purpose of alerting the Person of a posting, or (4) communicated to the Person
by any other form of electronic transmission consented to by the Person.
(c) Directors and Members may participate in, and hold a meeting by means of, a
telephone conference or other similar remote or electronic-communication system by means
of which all Persons participating in the meeting can hear each other. Participation in a
meeting involving remote communication will constitute presence in person at the meeting,
except where a Person participates in the meeting for the express purpose of objecting to the
transaction of any business on the ground that the meeting is not lawfully called or convened,
if (1) the Association implements reasonable measures to verify that each Person considered
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 17 of 20
present and permitted to vote at the meeting by means of remote communication is the
appropriate Person entitled to participate and vote, (2) the Association implements reasonable
measures to provide the Directors and Members at the meeting by means of remote
communication a reasonable opportunity to participate in the meeting and to vote on matters
submitted, including an opportunity to read or hear the proceedings of a meeting substantially
concurrently with the proceedings, and (3) the Association maintains a record of any vote or
other action taken at the meeting by means of remote communication.
12.3. Rules.
(a) The initial Association Rules, if, as, and when adopted, will be effective until
amended or supplemented by the Board of Directors, and are in addition to any rules and
regulations or other restrictions on use set forth in the Declaration.
(b) Subject to Section 12.1, the Board, under these Bylaws and the Declaration,
reserves the power to establish, make, and enforce compliance with any additional
Association Rules as may be necessary for the operation, use, and occupancy of the
Subdivision with the right to amend them from time to time, provided they do not conflict
with the Declaration. Copies of these Association Rules must be furnished to each Owner
before the date when they become effective. If any proposed amendment to the Association
Rules would affect less than all of the Lots, the amendment will not be effective without the
consent of the Owners of those Lots adversely affected by the amendment.
12.4. Abatement and Enjoinment. The violation of any Association Rule promulgated by the
Board, or the breach of any of these Bylaws, or the breach of any provision of the Declaration
will give the Board the right, in addition to any other rights set forth in the Declaration or in
these Bylaws, to do the following:
(a) To enter the Lot in which, or as to which, the violation or breach exists and to
(1) summarily abate and remove, at the expense of the Owner of the defaulting Lot, any
Person, structure, thing, or condition that may exist contrary to the intent and meaning of the
provisions of the Declaration or these Bylaws, and the Board will not be deemed guilty in
any manner of trespass, and (2) expel, remove, and put out such Person, structure, thing, or
condition, using any force as may be necessary in so doing, without being liable to
prosecution or any damages.
(b) To enjoin, abate, or remedy by appropriate legal proceedings, either at law or in
equity, the continuance of any breach.
12.5. Attestation. Adopted by the Board, on [DATE], and to be effective when recorded in
the Real Property/Official Records of Tarrant County, Texas.
(Signatures & Acknowledgement to follow)
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 18 of 20
ATTEST: ________________________________________
[NAME]
STATE OF TEXAS §
§
COUNTY OF TARRANT §
This instrument was acknowledged before me on _____________________ by [NAME].
___________________________
Notary Public – State of Texas
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 19 of 20
ATTEST: ________________________________________
[NAME]
STATE OF TEXAS §
§
COUNTY OF TARRANT §
This instrument was acknowledged before me on _____________________ by [NAME].
___________________________
Notary Public – State of Texas
_____________________________________________________________________________________________________________________
Bylaws of Maranatha Residential Homeowners Association, Inc. Page 20 of 20
ATTEST: ________________________________________
[NAME]
STATE OF TEXAS §
§
COUNTY OF TARRANT §
This instrument was acknowledged before me on _____________________ by [NAME].
___________________________
Notary Public – State of Texas
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 1 of 32
DECLARATION OF
COVENANTS, CONDITIONS, AND RESTRICTIONS FOR
MARANATHA RESIDENTIAL
SOUTHLAKE, TEXAS
STATE OF TEXAS §
§
COUNTY OF TARRANT §
This DECLARATION OF RESTRICTIVE COVENANTS, CONDITIONS, AND
RESTRICTIONS (“Declaration”) is made by SRI Southlake Villas, LLC, a Texas Limited
Liability Company (“Declarant”).
RECITALS
Declarant is the sole owner of any portion of the real property located in Tarrant County,
Texas, described as and constituting any part of the residential community development known
as “Maranatha Residential,” described on Exhibit “A” attached hereto and made part hereof, a
subdivision recorded or to be recorded in Tarrant County, Texas.
Declarant wants to impose on the real property certain protective covenants, conditions, and
restrictions, as described below, according to an established general plan for the improvement
and development of the Subdivision.
It is declared (a) that all of the Property described in Article II and Exhibit “A” attached hereto,
will be held, sold, conveyed, and occupied subject to the following easements, restrictions,
covenants, and conditions, which are for the purpose of protecting the value and desirability of,
and which will run with the Property and will be binding on all parties having any right, title,
or interest in or to the Property or any part of it, their heirs, successors, and assigns, and will
inure to the benefit of each owner, and (b) that each contract or deed that may later be executed
with regard to the Property or any portion of it will conclusively be held to have been executed,
delivered, and accepted subject to the following covenants, conditions, and restrictions
regardless of whether they are set forth or referred to in the contract or deed.
ARTICLE 1
DEFINITIONS
Unless the context specifies or requires otherwise, the following words and phrases when used
in this Declaration have the following meanings:
1.01. Architectural Committee. “Architectural Committee” means the committee created
according to these restrictions to review and approve plans for the construction of
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 2 of 32
Improvements on the Property.
1.02. Architectural Committee Rules. “Architectural Committee Rules” means the rules and
regulations adopted by the Architectural Committee, as amended from time to time.
1.03. Assessment. “Assessment” or “Assessments” means assessment(s) levied by the
Association under the terms and provisions of this Declaration.
1.04. Association. “Association” means and refers to Maranatha Residential Homeowners
Association, a Texas nonprofit corporation, which after its formation, but subject to the
provisions of this Declaration, shall have the power, duty and responsibility of maintaining and
administering the common properties, and collecting the assessments and charges hereinafter
prescribed; and have the right of administering and enforcing the Covenants, Conditions, and
Restrictions.
1.05. Association Rules. “Association Rules” means the rules and regulations adopted by the
Board of Maranatha Residential Homeowners Association, as amended from time to time.
1.06. Board. “Board” means the Board of Directors of the Maranatha Residential Homeowners
Association.
1.07. Builder. “Builder” means any builder approved in writing by Declarant or Architectural
Committee.
1.08. Bylaws. “Bylaws” means the Bylaws of the Maranatha Residential Homeowners
Association, which may be adopted by the Board, as amended from time to time.
1.09. Certificate of Formation. “Certificate of Formation” means the Certificate of Formation
of the Maranatha Residential Homeowners Association that may be filed in the office of the
Secretary of State of the State of Texas, if the Association is formed, and as amended from
time to time.
1.10. City. “City” means the City of Southlake, Texas.
1.11. Common Area and Facilities. “Common Area and Facilities” means any Lots and other
properties designated by Declarant and conveyed to the Association, if formed, along with any
exclusive easements and other areas granted to Declarant or the Association and maintained for
the common benefit of the Owners. Common Area and Facilities may be designated by
Declarant and dedicated or otherwise conveyed to the Association, if formed, the Owners, or to
any public agency, authority, or utility from time to time and at any time. If and at the time
Declarant annexes additional real property to the Property in accordance with Section 2.02,
additional Common Area and Facilities may be designated.
1.12. Declarant. “Declarant” means SRI Southlake Villas, LLC, and its duly authorized
representatives or their successors or assigns. Any assignment of the rights of Declarant must
be expressly set forth in writing and the mere conveyance of a portion of the Property without
written assignment of the rights of Declarant will not be sufficient to constitute an assignment
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 3 of 32
of the rights of Declarant under this Declaration. No person or entity purchasing one or more
Lots from SRI Southlake Villas, LLC in the ordinary course of business shall be considered as
“Declarant.”
1.13. Declaration. “Declaration” means this instrument as amended from time to time.
1.14. Improvement. “Improvement” means every structure and all appurtenances to structures
of every type and kind, including but not limited to buildings, outbuildings, storage sheds,
patios, tennis courts, swimming pools, garages, storage buildings, fences, screening walls ,
retaining walls, stairs, decks, landscaping, poles, signs, exterior air conditioning, water-softener
fixtures or equipment, and poles, pumps, wells, tanks, reservoirs, pipes, lines, meters, antennas,
towers, and other facilities used in connection with water, sewer, gas, electric, telephone,
regular or cable television, or other utilities.
1.15. Living Unit. “Living Unit” means and refers to a single-family residence and the
attached garage serving it.
1.16. Lot. “Lot” or “Lots” means any parcel or parcels of land within the Property shown as a
subdivided lot on any recorded Plat of the Subdivision, together with all Improvements located
on the parcel or parcels.
1.17. Masonry. “Masonry” means stucco, stone (natural, precast, or manufactured), and brick,
fiber-cement material as approved by the Architectural Committee, stone veneer, or other
siding materials.
1.18. Member. “Member” or “Members” means and refers to each Owner of a Lot, any
Person(s) holding membership rights in the Association.
1.19. Mortgage. “Mortgage” or “Mortgages” means any mortgage(s) or deed(s) of trust
covering any portion of the Property given to secure the payment of a debt.
1.20. Mortgagee. “Mortgagee” or “Mortgagees” means the holder or holders of any Mortgage
or Mortgages.
1.21. Owner. “Owner” or “Owners” means the Person(s), including Declarant, holding a fee-
simple interest in any portion of in any Lot subject to these Covenants, Conditions, and
Restrictions; however, the word “Owner” does not include persons(s) or entity(ies) who hold a
bona fide lien or interest in a Lot as security for the performance of an obligation, including the
Mortgagee of a Mortgage.
1.22. Person. “Person” or “Persons” means any individual(s), entity, or entities having the
legal right to hold title to real property.
1.23. Plans and Specifications. “Plans and Specifications” means any and all documents
designed to guide or control the construction or erection of any Improvement, including but not
limited to those indicating location, size, shape, configuration, materials, site plans, excavation
and grading plans, foundation plans, drainage plans, landscaping and fencing plans, elevation
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 4 of 32
drawings, floor plans, specifications on all building products and construction techniques,
samples of exterior colors, plans for utility services, and all other documentation or information
relevant to such Improvement.
1.24. Plat. “Plat” or “Plats” means the subdivision plat of Maranatha Residential, an addition
to the City of Southlake, Tarrant County, Texas, filed for registration on *** at ***am under
the instrument number ***.
1.25. Property. “Property” means all of the real property now or later constituting any portion,
phase, or section of the Subdivision.
1.26. Restrictions. “Restrictions” means this Declaration, as amended from time to time,
together with the Architectural Committee Rules, the Association Rules, the Certificate of
Formation, and Bylaws.
1.27. Subdivision. “Subdivision” means Maranatha Residential, an addition to the City of
Southlake in Tarrant County, Texas, according to the Plats.
1.28. Temporary Office. “Temporary Office” means any temporary construction or marketing
trailer, office, or building installed or constructed by Declarant or Builder on any Lot owned by
Declarant or the Builder, respectively, that is used for the storage of equipment or for office,
administrative, sales, or marketing purposes during the construction and sale of Lots and
Improvements within the Subdivision.
ARTICLE 2
DEVELOPMENT OF THE PROPERTY
2.01. Existing Property. The existing property is located in the City of Southlake, Tarrant
County, Texas, and is described in detail on Exhibit “A” attached hereto and incorporated
herein by reference for all purposes.
2.02. Addition of Land. Declarant may, at any time and from time to time, without the
consent of any other Owners, the Board and/or the Association, add land to the Property, and
on such addition, this Declaration and the covenants, conditions, restrictions, and obligations
set forth in it will apply to the added land, and the rights, privileges, duties, and liabilities of
the Persons subject to this Declaration will be the same with respect to the added land as with
respect to the lands originally covered by this Declaration. With respect to any and all portions
of the Common Area, Declarant, until Declarant no longer owns record title to any Lot or the
tenth (10) anniversary of the date this Declaration was recorded in the Official Records of Real
Property of Tarrant County, Texas, whichever is the last to occur, shall have the right and
option (without the joinder and consent of any person or entity, save and except any consent,
joinder or approval required by the City of Southlake or any other governmental agency having
appropriate jurisdiction over the Common Area) to: (i) zone, rezone, or seek and obtain
variances or permits of any kind or nature whatsoever upon or within the Common Area; (ii)
re-plat or redesign the shape or configuration of the Common Area; and (iii) seek and obtain
any and all permits licenses or exemptions from any and all governmental agencies exercising
jurisdiction over the Common Area. To add land to the Property under this Declaration,
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 5 of 32
Declarant will be required only to record in the Official Records of Real Property of Tarrant
County, Texas, a notice of addition of land containing the following provisions:
(a) A reference to this Declaration, which must in clude the book and page numbers of
the Official Records of Real Property of Tarrant County, Texas, in which this Declaration is
recorded.
(b) A statement that the provisions of this Declaration will apply to the added land.
(c) A legal description of the added land.
ARTICLE 3
GENERAL RESTRICTIONS
All of the Property will be owned, held, encumbered, leased, used, occupied, and enjoyed
subject to the following limitations and restrictions:
3.01. Subdividing and Combining of Lots. No Lot will be further divided or subdivided, nor
may any easements on or other interests relating to a Lot less than the whole be conveyed by
the Owner of the Lot without the prior written approval of the Architectural Committee;
however, when Declarant is the Owner, Declarant may further divide and subdivide any Lot
and convey any easements or other interests less than the whole, all without the approval of the
Architectural Committee. Any Owner owning two or more adjoining Lots may consolidate
such Lots into a single building location for the purposes of constructing one (1) residential
structure if approved in writing by the Declarant and Architectural Committee. Owner shall
continue to pay assessments on such Lots as if such Lots had not been consolidated and shall
be entitled to one vote for each Lot owned by such Owner. Any such consolidation shall give
consideration to easements as shown and provided for on the Plat and any required
abandonment or relocation of any such easements shall require the prior written approval of
Declarant as well as the prior written approval of any utility company having the right to the
use of such easements. Combining of portions of Lots into a single building site is prohibited.
No residential Lot shall contain less than forty-three thousand five hundred sixty square feet
(43,560 SF) of area.
3.02. Hazardous Activities. No activities will be conducted on the Property and no
Improvements constructed on the Property that are or might be unsafe o r hazardous to any
Person or property. Without limiting the generality of the foregoing, no firearms or fireworks
will be discharged on the Property, and no open fires will be permitted except within safe and
well-designed fireplaces or in contained barbecue units while attended and in use for cooking
purposes.
3.03. Insurance Rates. Nothing will be done or kept on the Property that would increase the
rate of insurance or cause the cancellation of insurance on any Lot or any of the Improvements
located on any Lot.
3.04. Mining and Drilling. No portion of the Property will be used for the purpose of mining,
quarrying, drilling, boring, or exploring for or removing oil, gas, or other hydrocarbons,
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 6 of 32
minerals of any kind, rocks, stones, sand, gravel, aggregate, or earth.
3.05. Noise and Nuisances. No noise from exterior speakers, horns, whistles, bells, or other
sound devices or other nuisance will be permitted to exist or operate on any po rtion of the
Property so as to be offensive or detrimental to any other portion of the Property or to its
occupants. No exterior lighting of any sort will be installed or maintained on a Lot where the
light source is offensive or a nuisance to neighboring property (except reasonable security or
landscape lighting that has the approval of the Architectural Committee).
3.06. Animals – Household Pets. No animals, including pigs, hogs, swine, roosters, fowl,
wild animals, horses, cattle, sheep, goats, or any other type of animal not considered to be a
domestic household pet within the ordinary meaning and interpretation of these words, may be
kept, maintained, or cared for on the Property. Any dog that has been determined to be
“dangerous” by the City or any other political subdivision, animal-control authority, or
governmental agency, will never be maintained, kept, or cared for on the Property. No animal
will be allowed to make an unreasonable amount of noise, or to become a nuisance, and no
domestic pets will be allowed on the Property other than on the Lot of its Owner unless
confined to a leash. No animal may be stabled, maintained, kept, cared for, or boarded for hire
or remuneration on the Property, and no kennels or breeding operation will be allowed. No
animal will be allowed to run at large, and all animals must be kept within enclosed areas that
must be clean, sanitary, and reasonably free of refuse, insects, and waste at all times. An
enclosed area must be constructed in accordance with plans approved by the Architectural
Committee, must be of reasonable design and construction to adequately contain animals in
accordance with the provisions of this Declaration, and must be screened so as no t to be visible
from any other portion of the Property.
3.07. Rubbish and Debris. No rubbish or debris of any kind will be placed or permitted to
accumulate on the Property, and no odors will be permitted to arise from it so as to make the
Property or any portion of it unsanitary, unsightly, offensive, or detrimental to any other
property or to its occupants. Refuse, garbage, and trash must be kept at all times in covered
containers, and the containers must be kept within enclosed structures or appropriat ely
screened from view. Each Owner must contract with an independent disposal service to collect
all garbage or other wastes if collection service is not provided by a governmental entity.
3.08. Maintenance; Mowing. Each Owner must keep all shrubs, trees, grass, and plantings of
every kind on the Owner’s Lot cultivated, pruned, free of trash, and other unsightly material.
All Improvements on any Lot must at all times be kept in good condition and repair and
adequately painted or otherwise maintained by the Owner of the Lot. Declarant, the
Association, and the Architectural Committee have the right at any reasonable time to enter on
any Lot to replace, maintain, and cultivate shrubs, trees, grass, or other plantings as deemed
necessary, to paint, repair, or otherwise maintain any Improvements in need of maintenance,
and to charge the cost to the Owner of the Lot in the same manner as provided for the
Association in Section 6.04(e).
3.09. Antennae. No exterior radio or television antenna or aerial or satellite dish receiver that
is visible from any adjacent street within the Subdivision will be erected or maintained on any
Lot without obtaining the Architectural Committee’s written consent.
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 7 of 32
3.10. Signs. No sign of any kind will be displayed to the public view on any Lot without the
prior written approval of the Architectural Committee, except for (a) signs that are part of
Declarant’s overall marketing or construction plans or activities for the Property, (b) one (1)
sign no more than five (5) square feet advertising any property within the Subdivision for sale
or rent, and (c) one (1) ground-mounted sign no more than five (5) square feet advertising no
more than one (1) political candidate or ballot item for election. All merchandising,
advertising, and sales programming signs are subject to the approval of the Architectural
Committee.
3.11. Water Wells & Tanks, Geo Thermal. The Architectural Committee may approve the
location of any tank used or proposed in connection with a single-family residential structure,
including tanks for water and including swimming-pool filter tanks. No elevated tanks of any
kind will be erected, placed, or permitted on any Lot. All tanks must be screened so as not to
be visible from any other part of the Property. No individual water-supply systems will be
permitted on any Lot, including but not limited to cesspools, or water-collection tanks;
however, water wells (subject to all government permitting processes), rain barrels and rain
harvesting devices will be permitted subject to the right of the Architectural Committee to
approve the location, size, type, and shielding of, and the materials used in the construction of,
any such rain barrels, rain harvesting devices, and related appurtenances. The Architectural
Committee may approve the use of Geo Thermal devices.
3.12. Temporary Structures. No tent, shack, gazebos, greenhouses, storage shed, children’s
playhouses, tree houses, or other temporary building, improvement, or structure will be placed
on the Property without the prior written approval of the Architectural Committee; however,
Temporary Offices and temporary structures necessary for the storage of tools and equipment
or for office space for architects, Builder, and foremen during actual construction may be
maintained with Declarant’s approval, approval to include the nature, size, duration, and
location of the Temporary Office or structure. Despite any provision in this Declaration to the
contrary, an Owner will be permitted, without Architectural Committee approval, to erect o ne
(1) outbuilding on the Owner’s Lot if (a) the exterior of the outbuilding is constructed of the
same or substantially similar materials as the exterior of any residence located on the Lot, and
(b) the outbuilding is constructed within building setback lines, in accordance with applicable
building codes of the governmental entity having jurisdiction over the Property, and with all
required governmental permits. The Architectural Committee is entitled to determine, in its
sole and absolute discretion, whether an outbuilding constructed on any Lot complies with the
foregoing requirements relating to size, height, fence enclosure, and construction materials.
3.13. Unsightly Articles; Vehicles. No article deemed to be unsightly by the Architectural
Committee will be permitted to remain on any Lot so as to be visible from an adjoining
property or from public or private thoroughfares. Without limiting the generality of the
foregoing, trailers, graders, trucks other than pickups, boats, tractors, campers, wagons, buses,
motorcycles, all-terrain vehicles, motor scooters, sports equipment (such as volleyball nets,
soccer goals or portable basketball goals), and garden-maintenance equipment must be kept
enclosed in a structure at all times. Service areas, storage areas, compost piles, and facilities for
hanging, drying, or airing clothing or household fabrics must be appropriately screened from
view, and no lumber, grass, plant waste, shrub or tree clippings, metals, bulk materials, scrap,
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 8 of 32
refuse, or trash will be kept, stored, or allowed to accumulate on any portion of the Propert y
unless it is within an enclosed structure or is appropriately screened from view. Each single-
family residential structure constructed within the Property must have sufficient garage space,
as approved by the Architectural Committee, to house all vehicles to be kept on the Lot. Lot
Owners may not keep more than two (2) automobiles so that they are visible from any other
portion of the Property for any period in excess of seventy-two (72) hours. No automobiles or
other above-mentioned articles or vehicles may be parked overnight on any roadway within the
Property. No (a) racing vehicles or (b) other vehicles (including, but not limited to,
motorcycles or motor scooters) that are inoperable or do not have a current license tag are
permitted to remain visible on any Lot or to be parked on any roadway within the Subdivision.
No commercial vehicles larger than a standard three-quarter (3/4) ton pickup truck or standard
two-axle passenger van are permitted to remain on any Lot or to be parked on any roadway
within the Subdivision. No repair or maintenance work may be done on any of the foregoing or
on any automobile (other than minor emergency repairs) except in enclosed garages or other
structures.
3.14. Mobile Homes, Travel Trailers, and Recreational Vehicles. No mobile homes may be
parked or placed on any Lot or used as a residence, either temporary or permanent, at any time.
For the convenience of guests visiting Owners, motor homes, travel trailers, or recreational
vehicles may be parked on the Owner’s Lot for a maximum of twenty-four (24) hours every
thirty (30) days, but such vehicles may not be parked on the street at anytime.
3.15. Compliance with the Restrictions. Each Owner must comply strictly with the
provisions of the Restrictions as amended from time to time. Failure to comply with any of the
Restrictions constitutes a violation of this Declaration and gives rise to a cause of action to
recover amounts due for damages or injunctive relief or both, maintainable by the Declarant,
the Architectural Committee, the Board on behalf of the Association, an aggrieved Owner.
3.16. Liability of Owners for Damage to Common Area and Facilities. No Owner will in
any way alter, modify, add to, or otherwise perform any work on the Common Area and
Facilities without the prior written approval of the Board. Each Owner is liable to the
Declarant, the Association, the Owners, or any public agency, authority, or utility if the
Common Area and Facilities have been dedicated or otherwise conveyed to any of these
parties, for any and all damages to (a) the Common Area and Facilities or (b) any
Improvements constructed on any Lot, the maintenance of which has been assumed by any of
these parties, which damages were caused by the neglect, misuse, or negligence of an Owner or
the Owner’s family, or by any tenant or other occupant of the Owner’s Lot, or an y guest or
invitee of the Owner. The full cost of all repairs of the damage will be an Assessment against
the Owner’s Lot, secured by a lien against the Owner’s Lot and collectable in the same manner
as provided for in Section 8.06, including but not limited to foreclosure of the lien.
3.17. Basketball Goals. Permanent basketball goals are allowed but must be approved by the
Architectural Committee before installation. The permanent basketball goal must be properly
maintained and painted, with nets kept in good repair and installed in the rear of the house and
out of street view. Portable goals are not allowed at anytime.
3.18. No Warranty of Enforceability. While Declarant has no reason to believe that any of
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 9 of 32
the restrictive covenants or other terms and provisions contained in this Article or elsewhere in
this Declaration are or may be invalid or unenforceable for any re ason or to any extent,
Declarant makes no warranty or representation as to the present or future validity or
enforceability of any restrictive covenants, terms, or provisions. Any Owner acquiring a Lot in
reliance on one or more of the restrictive covenants, terms, or provisions assumes all risks of
their validity and enforceability and, by acquiring the Lot, agrees to hold Declarant harmless if
they are held to be invalid or unenforceable.
ARTICLE 4
USE AND CONSTRUCTION RESTRICTIONS
4.01. Approval for Construction. No Improvements will be constructed on any Lot without
the prior written approval of the Architectural Committee.
4.02. Use. All Lots, unless dedicated to the Association as Common Area and Facilities, will
be improved and used solely for single-family residential use, inclusive of an attached private
garage for not more than five (5) cars, fencing, and other Improvements as are necessary or
customarily incident to residential use. Despite any provision of this Declaration to the
contrary, the Declarant may use a select number of Lots owned by Declarant for Temporary
Offices within the Subdivision.
4.03. Homebuilder and Architect. All Homebuilders and architects must be pre-approved, in
writing, by the Architectural Committee.
4.04. Rentals. Nothing in this Declaration will prevent the rental of any Lot and the
Improvements on it by the Owner for residential purposes, provided that all rentals must be for
terms of at least one (1) year.
4.05. Dwelling Height. No single-family dwelling greater than two (2) stories in height may be
constructed on any Lot without the prior written approval of the Architectural Committee.
4.06. Fences. Unless otherwise approved by the Architectural Committee, all fences on Lots
must be six (6) feet in height and must be constructed with black wrought iron or decorative
metal. Any fence fronting on a street must be constructed of black wrought iron or decorative
metal, and/or stone or brick wing walls matching the exterior of the dwelling and must be six
(6) feet in height. Any side yard fence must be six (6) feet in height and constructed with black
wrought iron or decorative metal. The backyard fence must also be constructed with black
wrought iron or decorative metal. The Architectural Committee has the right to approve
deviations from these requirements relating to the style and materials to be used based on the
location of the Property. It is the intent to maintain visual continuity, especially along streets,
as per the design standard set forth in Exhibit “B”.
4.07. Dwelling Size; Building Materials. All dwellings will contain at least four thousand five
hundred (4500 SF) square feet of enclosed living space, exclusive of porches (open or
covered), decks, garages, and carports. Both first and second stories with have a minimum
plate height of ten (10) feet. The Architectural Committee must approve all building materials,
and only new building materials (except for used brick) will be used for constructing any
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 10 of 32
Improvements. Subject to the City of Southlake’s building code standards allowing such
provisions, the total exterior surface of all residential dwellings shall be of fire resistant
construction having not less than ninety percent (90%) of the total exterior walls above grade
level, excluding doors and windows and recessed second floor walls, constructed of brick no
larger than a “Queen” size, stone, stucco, masonry products, or cement fiber material approved
by the Architectural Committee or material of equal characteristics in accordance with the City
of Southlake’s building code and fire prevention code. Strict adherence to this rule shall not be
such as to prevent architectural creativity.
4.08. Garage. All exterior surfaces, especially any painted or stained wood surfaces (including,
without limitation, garage doors) must be maintained in good condition.
4.09. Solar. The installation of solar panels on any roof or other portion of a residence that is
visible from any adjacent street is expressly prohibited without the prior written consent of the
Architectural Committee.
4.10. Windows. All street visible windows must be wood or aluminum windows with divided
light manufactured by Anderson, Pella Windows or windows of comparable quality approved
by the Architectural Committee, rear facing windows are not required to be divided light unless
such windows are not appropriate for the home style approved by the Architectural Committee.
Non-divided light windows will be allowed at the front elevation if such windows are
consistent with the vernacular of the home. Any windows that are visible from any residential
street shall be covered with draperies or blinds within sixty (60) days after the date on which
the main structure is occupied. All tin foil and newspaper window coverings are expressly
prohibited. Temporary paper shades are only allowed for 90 days after installation. No
window unit air-conditioning systems shall be permitted on any home.
4.11. Roofing Material. Roofing material is limited to clay or concrete tile, slate, earth tone
metal standing seam roofing material, or minimum thirty (30) year composition roof. In
addition, turrets and awnings may be constructed of copper standing seam material. The
Architectural Committee must approve the color of all roofing materials. Roofs must have a
minimum of 10/12 pitch, unless a different slope is approved by the Architectural Committee.
Exposed metal roof decks that reflect light in a glaring manner, such as galvanized-steel sheets,
and composite roofing tiles are specifically prohibited. Other roofing materials may be used
with the Architectural Committee’s written consent, which may specify a minimum quality or
grade of materials. All projections from a dwelling or other structure, including but not limited
to chimney flues, vents, gutters, downspouts, utility boxes, porches, railings, and exterior
stairways must match the color of the surface from which they project, or must be of a col or
approved by the Architectural Committee. No highly reflective finishes (other than glass,
which may not be mirrored) will be used on exterior surfaces (other than surfaces of hardware
fixtures), including, but not limited to, the exterior surfaces of any Improvements.
4.12. Garbage Containers. The Architectural Committee has the right to specify a specific
location on each Owner’s Lot in which garbage containers must be placed for trash-collection
service.
4.13. Landscaping. The front yard shall have a minimum of four (4) existing or planted 3”
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 11 of 32
caliper trees. The front and side yards of all Lots, from the front wall of the house, will be fully
sodded with St. Augustine, Bermuda, Prairie Buffalo Grass, or other sod, drought-resistant
landscaping, or water-conserving natural turf approved by the Architectural Committee within
sixty (60) days after the date on which carpet or flooring has been installed in the residence.
The Owner must keep the yard sufficiently watered to insure adequate growth of the grass.
The Owner must install an automatic sprinkler system, approved by the Architectural
Committee, for the purpose of producing sufficient water to preserve and maintain the
landscape in a healthy and attractive condition. At least two (2) three-inch (3”) diameter oak
tree(s) must be planted in the front yard of each Lot before the occupancy of the Living Unit
constructed on it. This requirement will be waived by the Architectural Committee if, in the
opinion of the Architectural Committee, adequate existing trees are retained. All other types of
trees, other than oak, which are approved, will be subject to the prior written approval of the
Architectural Committee.
EACH OWNER IS ADVISED THAT THERE ARE NO EXPRESS OR IMPLIED
WARRANTIES AS TO THE LIFE EXPECTANCY, VITALITY, OR FITNESS FOR
INTENDED PURPOSES OF ANY EXISITNG AND THEREAFTER PLACED
TREES OR SHRUBS LOCATED ON A LOT.
4.14. Retaining Walls. All side yard or front yard retaining walls that are visible from a street
will be constructed of stone veneer that matches the stone used at the subdivision entrance or
stone that matches Owner’s home. If the wall is over three and one-half (3 ½) feet tall it will
have a concrete wall with an appropriate concrete footing unless otherwise approved in writing
by the Architectural Committee. Any walls taller than four (4’) feet must be designed by a
reputable engineering firm and constructed in accordance with the plans of such firm and
approved in writing by the Architectural Committee.
4.15. Pools. A pool may not be constructed or installed without the prior written consent of the
Architecture Committee. All pool service equipment must be placed behind the fence line and
located in either a side yard or rear yard and must be landscaped so that it is not visible from
any residential street or any adjoining Lot.
4.16. Mail Boxes and Street Address Numbers . All mailboxes shall be the style as set forth
in Exhibit “C”. The Architectural Committee must approve all mailboxes.
4.17. Driveways. Driveways and parking pads must be surfaced with concrete or pavers. The
driveway must be bordered in a minimum of nine (9) inch brick or stone, along with a
landscaped perimeter and a 2-car parking pad on the Lot, other than the garage. All driveway
styles must be approved by the Architectural Committee.
4.18. Sidewalks. All public sidewalks must conform to City specifications and regulations and
be constructed of concrete. The Owner of each Lot must construct, at its sole cost and expense
and before occupying the Lot, a public sidewalk, located and designed in conformance with the
Plat, to the extent the Plat requires a public sidewalk on the Owner’s Lot.
4.19. Front Entry Surface. All front entry surfaces must be constructed of concrete, brick,
stone, slate or flagstone. All sidewalks and steps from the public sidewalk or front driveway to
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 12 of 32
the front entry must be constructed of concrete, brick, stone, slate or flagstone with brick or
stone borders.
4.20. Utility Pedestals. At no time shall landscaping or other changes be made in the location
of the utility pedestals that would impede drainage flow.
4.21. Exterior Lighting and Flagpoles. All exterior lighting (other than porch lighting, patio
lighting and indirect lighting) must first be approved in writing by the Architectural Committee
prior to installation. One flagpole will be permitted, however, the flagpole location must be
approved by the Architectural Committee prior to installation.
4.22. Tennis Court; Recreational Facilities. Tennis Courts and other recreational facilities
are not allowed unless approved in writing by the Architectural Committee prior to installation.
4.23. Loud Speakers. No radio, stereo, broadcast or loud speaker units or amplifiers of any
kind shall be placed upon or outside, or be directed to the outside, of any dwelling or other
improvement without the prior written approval of the Architectural Committee.
4.24. Playground Equipment. Any playground equipment, play forts, swings sets and other
outdoor yard items may not be in primary colors and must be approved in writing by the
Architectural Committee prior to installation.
4.25. Garages. Each single-family residential dwelling shall provide garage space for a
minimum of three (3) vehicles and a maximum of six (6) vehicles, unless stacked or tandem
style. Garages must not face front unless behind a motor court with gated entry. Garage doors
shall be closed at all times other than during periods of time when the Owner is going to or from
the garage for the purpose of moving vehicles in and out of the garage, working in the garage, or
doing other work on such Owners Lot which requires access to and from the garage. Garages
shall be used exclusively for the parking of vehicles and the storage of household goods
normally kept in garages but shall not be enclosed for use as residential living quarters or as
permanent storage facilities. All interiors garage walls shall be finished with drywall material
and painted or covered with other materials approved by the Architectural Board.
4.26. Drainage. There will be no interference with the established drainage patterns over any
of the Property, unless adequate provision is made for proper drainage and the Architectural
Committee approves the provision. All Lots shall be graded so that no storm water drainage
shall flow onto other lots except as may be shown on the engineer’s plans on file with the City
of Southlake, Texas. All drainage easements are for surface drainage and Owners may not
modify drainage gradients or block drainage easements with fencing, landscaping or other
structures or devices.
4.27. Private Drainage Easement. A Private Drainage Easement is located on certain lots
according to the Plat. No permanent structures are allowed to be built in this easement.
Landscaping including, without limitation, grass, underground sprinkler systems and trees as
approved in writing by the Architectural Committee may be built and maintained in this
easement.
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 13 of 32
4.28. Alteration or Removal of Improvements. Any construction, other than normal
maintenance, that in any way alters the exterior appearance of any Improvement or the removal
of any Improvement, will be performed only with the prior written approval of the
Architectural Committee.
4.29. Construction Activities. This Declaration will not be construed so as to unreasonably
interfere with or prevent normal construction activities during the construction of
improvements by an Owner (including Declarant) on any Lot within the Property. Specifically,
no construction activities will be deemed to constitute a nuisance or a violation of this
Declaration by reason of noise, dust, presence of vehicles or construction machiner y, posting
of signs, or similar activities, provided that the construction is pursued to completion with
reasonable diligence and conforms to usual construction practices in the area. If construction
on any Lot does not conform to usual practices in the ar ea as determined by the Architectural
Committee in its sole good-faith judgment, the Architectural Committee will have the authority
to seek an injunction to stop the construction. In addition, if during the course of construction
on any Lot there is excessive accumulation of debris of any kind that would make the Lot or
any portion of it unsanitary, unsightly, offensive, or detrimental to it or any other portion of the
Property, then the Architectural Committee may contract for or cause such debris to be
removed, and the Owner of the Lot will be liable for all expenses incurred in connection with
removal. Sunday construction is specifically prohibited.
4.30. Construction Completion Time. Once Owner purchases a Lot construction must
commence within one (1) year of closing unless Declarant or Board, in writing, provides Lot
Owner a time extension. Each residence constructed on each Lot and any other improvements
thereto shall be commenced and completed on or before one and one-half (1 ½) years after the
commencement of construction. For the purposes hereof, the term “commencement of
construction” shall be deemed to mean the date on which the foundation forms are set. In the
event that a residence is partially or totally damaged by fire or other causes, th e Owner of such
residence must either rebuild the residence or completely clear the Lot. In the event the Owner
desires to rebuild, the construction or restoration of the damaged residence, or portion thereof,
must commence within one hundred twenty (120) days after the occurrence causing the
damage. No construction or restoration shall commence, however, until plans and
specifications have submitted to the Architectural Committee and subsequently approved. In
the event the Owner does not desire to rebuild, the Owner must clear away all remaining debris
and restore the Lot to the condition in which it existed prior to the initial construction of the
damaged residence.
IN SOME INSTANCES, GOVERNMENTAL REQUIREMENTS MAY BE MORE OR
LESS RESTRICTIVE THAN THE PROVISIONS OF THE DECLARATION. IN
THE EVENT A CONFLICT EXISITS BETWEEN ANY SUCH GOVERNMENTAL
REQUIREMENT AND ANY REQUIREMENT OF THIS DECLARATION, THE
MOST RESTRICTIVE REQUIREMENT SHALL PREVAIL, EXCEPT IN
CIRCUMSTANCES WHERE COMPLIANCE WITH A MORE RESTRICTIVE
PROVISION OF THE DECLARATION WOULD RESULT IN A VIOLATION OF
MANDATORY APPLICABLE GOVERNMENTAL REQUIREMENTS, IN WHICH
EVENT THOSE GOVERNMENTAL REQUIREMEMENTS SHALL APPLY.
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 14 of 32
COMPLICANCE WITH MANDATORY GOVERNMENTAL REQUIREMENTS
WILL NOT RESULT IN THE BREACH OF THIS DECLARATION EVEN THOUGH
SUCH COMPLIANCE MAY RESULT IN NONCOMPLIANCE WITH THE
PROVISIONS OF THIS DECLARATION. WHERE A GOVERNMENTAL
REQUIREMENT DOES NOT CLEARLY CONFLICT WITH THE PROVISIONS OF
THIS DECLARATION BUT PERMITS ACTION THAT IS DIFFERENT FROM
THAT REQUIRED BY THIS DECLARATION, THE PROVISIONS OF THIS
DECLARATION SHALL PREVAIL AND CONTROL.
ARTICLE 5
COMMON AREA AND FACILITIES
5.01. Common Area and Facilities. No land within any Common Area and Facilities will be
improved, used, or occupied, except in the manner approved by Declarant, in its sole and
absolute discretion. This required approval will extend to the nature and type of use,
occupancy, and improvement. Declarant may, by written instrument, delegate its right to grant
this approval to the Board. Access to any Common Area and Facilities may be limite d to
Persons currently paying Assessments, fees, and other charges, or otherwise conditioned or
restricted, or made available to non-owners, all on the terms and conditions determined by
Declarant in its sole and absolute discretion.
5.02. Maintenance. Declarant may, but will not be obligated to, in its sole discretion, maintain
the Common Area and Facilities at its own cost and expense. If Declarant elects not to
maintain the Common Area and Facilities, maintenance of any Common Area and Facilities
will be the obligation of the Association and will be governed by Section 6.05, and
Assessments may be levied on the Owners under Article 8. Under no circumstances will
Declarant be liable to the Owners, the Association, or any other Person for maintaining or
failing to maintain the Common Area and Facilities.
5.03. Condemnation. If all or any part of the Common Area and Facilities is taken or
threatened to be taken by eminent domain or by power in the nature of eminent domain
(whether permanent or temporary), Declarant, or the Association, if applicable, will be entitled
to participate in the proceedings incident to the taking or threatened taking. The expense of
participation in the proceedings by the Association will be a common expense to be paid out of
Assessments. The Association is specifically authorized to obtain and to pay for such
assistance from attorneys, appraisers, architects, engineers, expert witnesses, and other Persons
as the Association, in its discretion, deems necessary or advisable to aid it in any matters
relating to the proceedings. All damages or awards for any taking will be the property of
Declarant, or, if applicable, deposited with the Association. The Association, if applicable, in
addition to the general powers set forth in this Declaration, will have the sole authority to
determine whether to contest or defend any proceedings, to make any settlement with respect
to any proceedings, or to convey the property to the condemning authority in lieu of
condemnation.
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 15 of 32
ARTICLE 6
THE ASSOCIATION
6.01. Organization. The Association is a nonprofit corporation created for the purposes,
charged with the duties, and vested with the powers prescribed by law or set forth in its
Certificate of Formation and Bylaws or in this Declaration. Neither the Certificate of
Formation nor Bylaws will for any reason be amended or otherwise changed or interpreted so
as to be inconsistent with this Declaration.
6.02. Membership. Any Person who is or who becomes an Owner of a Lot will automatically
become a Member of the Association and must remain a Member of the Association in good
standing. Membership will be appurtenant to and will run with the ownership of the Lot that
qualifies the Owner for membership, and membership may not be severed from, or in any way
transferred, pledged, mortgaged, or alienated except together with the title to th e Lot. The
Board may declare that an Owner is not a Member in good standing because of past unpaid
dues, fines, late charges, interest, legal fees, and/or any other assessments of any nature. The
Board may temporarily suspend the voting rights of any Member who is not in good standing
until the date when such past, unpaid amounts are paid in full.
6.03. Voting Rights. There will be two classes of membership for the purpose of voting on any
Association matter.
Class A: Class “A” Members will include each Owner (excluding Declarant) of a Lot
within the Property, and each Owner will have one (1) vote for each Lot owned. When
more than one person holds such interest or interests in any Lot, all such persons shall be
Members, and the vote for such Lot shall be exercised as they, among themselves,
determine, but in no event shall more than one (1) vote be cast with respect to any such
Lot.
Class B: Class “B” Members will be the Declarant, and Declarant will have thirteen (13)
votes for each Lot it owns. The Class B Membership will convert to a Class A
Membership when (a) Declarant has conveyed all Lots to owners or (b) Declarant
voluntarily converts the Class B Membership to a Class A Membership by written
instrument recorded in the Real Property/Official/Deed Records of Tarrant County, Texas,
whichever occurs first.
Quorum, Notice, and Voting Requirements – The quorum, notice and voting
requirements of and pertaining to the Association are set forth within the Articles of
Incorporation and Bylaws of the Association, as may be amended from time to time.
6.04. Management, Powers and Authority of the Association and Board. The affairs of the
Association shall be managed by a Board of Directors (“Board”). The initial Board Directors
shall consist of three (3) Directors. Declarant will have the right to appoint and remove the
Board of Directors until a Change In Control. The Association will have the powers of a Texas
nonprofit corporation, subject only to the limitations expressly set forth in this Declaration. It
will further have the power to do and perform any and all acts that may be necessary or proper
for or incidental to the exercise of any of the express powers granted to it by the laws of Texas
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 16 of 32
or by this Declaration. Without in any way limiting the generality of the two preceding
sentences, the Association and the Board, acting on behalf of the Association, will have the
following powers and authority:
(a) Rules and Bylaws. To make, establish, promulgate, amend, repeal, and re-enact the
Association Rules and Bylaws. The Board may establish the content of the Association Rules
and Bylaws, provided that they do not conflict with this Declaration.
(b) Insurance. To obtain and maintain in effect policies of insurance that, in the
opinion of the Board, are reasonably necessary or appropriate to carry out the Association’s
functions.
(c) Records. To keep books and records, including financial records, of the
Association’s affairs.
(d) Assessments. To levy Assessments as provided in Article 8. An Assessment is
defined as the amount that must be levied in the manner and against the property set forth in
Article 8 in order to raise the total amount for which the levy in question is being made.
(e) Right of Entry and Enforcement. To only enter an Owners lot after twenty-four
(24) hours written notice, without being liable to any Owner, for the purpose of enforcing the
Restrictions or for the purpose of maintaining or repairing any area, Improvement, or other
facility to conform to the Restrictions, and the expense incurred by the Association in
connection with the entry on any Lot and the maintenance and repair work conducted on it
will be a personal obligation of the Owner of the Lot entered on, will be a lien o n the Lot
entered on and the Improvements on the Lot, and will be enforced in the same manner and to
the same extent as provided in Article 8 for regular Assessments. The Association will have
the power and authority from time to time, in its own name and on its own behalf, or in the
name of and on behalf of any Owner who consents to it, to commence and maintain actions
and suits to enforce, by mandatory injunction or otherwise, or to restrain and enjoin, any
breach or threatened breach of the Restrictions. The Association is also authorized to settle
claims, enforce liens, and take all action as it may deem necessary or expedient to enforce the
Restrictions; however, the Board will never be authorized to expend any Association funds
for the purpose of bringing suit against Declarant, any Builder, and any of their respective
successors and assigns.
(f) Legal and Accounting Services. To retain and pay for legal and accounting
services necessary or proper in the operation of the Association.
(g) To enter into contracts, maintain one or more bank accounts, and generally, to
have all the powers necessary or incidental to the operation and management of the
Association
(h) To make available to each Owner within ninety (90) days after the end of each
year an annual report.
6.05. Common Area and Facilities. Subject to and in accordance with this Declaration, the
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 17 of 32
Association, acting through the Board, will have the following duties:
(a) To accept, own, operate, and maintain all Common Area and Facilities that may be
conveyed or leased to it by Declarant, together with all Improvements of any kind and for
any purpose that may be located in those areas, and to accept, own, operate, and maintain all
other property, real or personal, conveyed or leased to the Association by Declarant and to
maintain in good repair and condition all lands, improvements, and other Association
property owned by or leased to the Association. Such maintenance will include, but will not
be limited to, painting, mowing, removing rubbish or debris of any kind, paving and
maintenance of the private street and curbs, entry gate and associated security features.
(b) To pay all real-property taxes, personal-property taxes, and other taxes and
Assessments levied on or with respect to Common Area and Facilities or any other property
owned by or leased to the Association to the extent that the taxes and Assessments are not
levied directly on the Members of the Association. The Association will have all rights
granted by law to contest the legality of the amount of the taxes and Assessments.
(c) To take out and maintain current a policy of liability-insurance coverage to cover
accidental bodily injury or death caused by the use and enjoyment of the Common Area and
Facilities. This insurance will be in an amount, as the Board deems appropriate.
(d) To borrow funds to pay costs of operation, secured by assignment or pledge of
rights against delinquent Owners, if the Board sees fit or with prior written consent of fifty-
one percent (51%) of Members secured by such assets of the Association as deemed
appropriate by the lender and the Association.
(e) The right of Declarant and/or the Association to dedicate or transfer all or any part
of the Common Properties to any municipal corporation, public agency, authority or utility
company for such purposes and upon such conditions as may be agreed upon by Declarant
and the Members having a majority of the outstanding eligible votes of the Association.
(f) The right of Declarant and/or the Association to convey, sell or lease all or part of
the Common Properties upon such terms and conditions as may be agreed upon by Declarant
and the members having a majority of the outstanding eligible votes of the Association.
(g) The right of the Declarant or the Association to enter into and execute contracts
with the owner-operators of any community antenna television system or other similar
operations such as telephones, or telecommunications for the purpose of extending cable,
telephone, computer or telecommunications equipment or utility service on, over or under the
Common Properties ultimately provide service to one or more of the Lots.
(h) The Declarant and Association hereby acknowledge that the street within the
development is “private” and shall bear all maintenance responsibilities and associated costs.
(i) Notwithstanding the fact that the street is a private street whose responsibility for
maintenance belongs to the Declarant and Association, there shall be no parking allowed on
the “inside” of the cul-de-sac located at the southern end of the private street. The City of
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 18 of 32
Southlake is given the explicit right to enforce the no-parking restriction without further
notice or consultation with the Declarant, Association or any property Owner.
ARTICLE 7
ARCHITECTURAL COMMITTEE
Preamble
Maranatha Residential is not set up to be developed as a single or limited number of
architectural styles, but rather approval of architectural plans will be based on adherence
to the details of the architectural style or vernacular of the design of the house.
7.01. Membership of Architectural Committee. The Architectural Committee will consist of
at least three (3) voting Members (“Voting Members”). Declarant and its successors or assigns
will have the right to appoint and remove all Voting Members of the Architectural Committee.
Declarant may delegate this right to the Board by written instrument after the Declarant no
longer owns any lots. After the Declarant delegates this right, the Board will have the right to
appoint and remove all Voting Members of the Architectural Committee. The following
Persons are designated as the initial Voting Members of the Architectural Committee:
1. [NAMES]
2. [NAMES]
3. [NAMES]
7.02. Action by Architectural Committee. Items presented to the Architectural Committee
will be decided by fifty-one percent (51%) of the Voting Members. The Architectural
Committee shall not be liable for damages to anyone submitting plans to it for approval or to
any Owner or occupant of the Property by reason of error or mistake in judgment, negligence,
or nonfeasance arising out of or in connection with the approval or disapproval or failure to
approve any such plans. No approval by the Architectural Committee shall constitute or be
deemed to constitute any representation or warranty of the adequacy or fitness of any
improvements approved by the Architectural Committee nor shall the Architectural Committee
have any liability regarding such adequacy or fitness.
7.03. Term. Each Voting Member of the Architectural Committee will hold office until such
time as he/she has resigned or has been removed or his/her successor has been appointed, as
provided in this Declaration. If any Voting Member dies or resigns, the remaining Voting
Member or Voting Members will have full authority to act until the Declarant or Board has
designated a replacement Voting Member or Voting Members. Neither the members of the
Architectural Committee nor its designated representative shall be entitled to any compensation
for services performed pursuant to this Declaration.
7.04. Adoption of Rules. The Architectural Committee may adopt any procedural and
substantive rules, not in conflict with this Declaration, that it deems necessary or proper for the
performance of its duties, including but not limited to a building code, a fire code, a housing
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 19 of 32
code, and other similar codes as it may deem necessary and desirable.
7.05. Review of Proposed Construction. Whenever in this Declaration the approval of the
Architectural Committee is required, it will have the right to consider all of the Plans and
Specifications for the Improvement or proposal in question and all other facts that, in its sole
discretion, are relevant. Except as otherwise specifically provided in this Declaration,
before the commencement of any construction of any Improvement on the Property or
any portion of it, the Plans and Specifications must be submitted to the Architectural
Committee, and construction may not commence unless and until the Architectural
Committee has approved the Plans and Specifications in writing. The Architectural
Committee will consider and act on any and all Plans and Specifications submitted for its
approval under this Declaration and perform the other duties assigned to it by this Declaration
or as from time to time assigned to it by the Board. The Architectural Committee may also
inspect any construction in progress to ensure its conformance with Plans and Specifications
approved by the Architectural Committee. The Architectural Committee may review Plans and
Specifications submitted for its review and any other information it deems proper. Until the
Architectural Committee receives any information or documents it deems necessary, it may
postpone review of any Plans and Specifications submitted for approval. No Improvement will
be allowed on any Lot that is of such size or architectural design or involves the use of such
landscaping, color schemes, exterior finishes, and materials and similar features as to be
incompatible with development within the Property and the surrounding area. The
Architectural Committee will have the authority to disapprove any proposed Improvement
based on the restrictions set forth in the preceding sentence and the decision of the
Architectural Committee will be final and binding if it is made in good faith. The A rchitectural
Committee will not be responsible for reviewing any proposed Improvement, nor will its
approval of any Plans or Specifications or inspection of any construction in progress be
deemed approval from the standpoint of structural safety, engineering soundness, or
conformance with building or other codes.
7.06. Variance. The Architectural Committee may grant variances from compliance with any
of the provisions of this Declaration when, in the opinion of the Architectural Committee, in its
sole and absolute discretion, the variance will not impair or detract from the high-quality
development of the Property and the variance is justified due to unusual or aesthetic
considerations or unusual circumstances. Despite anything to the contrary in this Declaration,
the Architectural Committee is authorized, at its sole discretion, to waive any requirements
relating to garages (including size), carports, dwelling size, Masonry requirements, fences, and
setbacks, and the decision will be binding on all Owners of Property encumbered by this
Declaration. All variances must be evidenced by written instrument in recordable form, and
must be signed by at least fifty-one percent (51%) of the Voting Members of the Architectural
Committee. The granting of a variance will not operate to waive or amend any of the terms or
provisions of the covenants and restrictions applicable to the Lots for any purpose except as to
the particular property and the particular instance covered by the variance, and a variance will
not be considered to establish a precedent or future waiver, modification, or amendment of the
terms and provisions of this Declaration.
7.07. Actions of the Architectural Committee. The Architectural Committee may, by a
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 20 of 32
resolution unanimously adopted in writing, designate one (1) or two (2) of its members or an
agent acting on its behalf to take any action or perform any duties for and on behalf of the
Architectural Committee. In the absence of a designation, the vote of the majority of all of the
members of the Architectural Committee taken without a meeting will constitute an act of the
Architectural Committee. Despite anything to the contrary, if the Architectural Committee fails
to respond to a request for approval of Plans and Specifications within thirty (30) days of
receiving all required information, the Architectural Committee will be deemed to have
approved the Plans and Specifications.
7.08. No Waiver of Future Approvals. The approval or consent of the Architectural
Committee to any Plans or Specifications for any work done or proposed or in connection with
any other matter requiring the approval or consent of the Architectural Committee will not be
deemed to constitute a waiver of any right to withhold approval or consent as to any Plans and
Specifications or any other matter subsequently or additionally submitted for approval or
consent by the same or a different Person.
7.09. Work in Progress. The Architectural Committee, at its option, may inspect all work in
progress to ensure compliance with approved Plans and Specifications.
7.10. Address. Plans and Specifications will be submitted to the Architectural Committee at
[ADDRESS] or at any other address as may be designated from time to time.
7.11. Fees. The Architectural Committee will have the right to require a reasonable submission
fee for each set of Plans and Specifications submitted for its review.
7.12. Approval. The approval by the Architectural Committee of any plans and/or
specifications for the construction of any dwelling or other improvements shall not constitute
any representation or warranty by the Declarant, Architectural Committee, or Association that
such plans and specifications, dwelling and/or other improvements comply with any applicable
laws, rules, ordinances, good and prudent design, engineering and construction practices or
other building standards or that such dwelling and/or other improvements are safe for human
use and habitation. The Declarant, Architectural Committee, or Association (and the officers,
directors, partners, employees and agents of Declarant) shall have no personal liability in
connection with their approval or disapproval of any plans or specifications or other request
made to the Declarant and/or Architectural Committee. It is the sole and exclusive
responsibility of the Owner to determine that such Owner’s plans and specifications comply
with all such requirements and practices.
ARTICLE 8
FUNDS AND ASSESSMENTS
8.01. Assessments.
(a) The Association may from time to time levy Assessments against each Lot. The
level of Assessments will be equal and uniform between all Lots.
(b) The obligation to pay an Assessment will arise at the time Owner purchases the
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 21 of 32
Lot, the Assessment will be prorated as of the date when the obligation first arose in
proportion to the amount of the Assessment year or other period remaining after that date.
(c) Each unpaid Assessment, together with the interest on it and the costs o f
collection, will be the personal obligation of the Owner of the Lot against which the
Assessment fell due, and will become a vendor’s lien against the Lot and all Improvements
on it. The Association may enforce payment of Assessments in accordance with the
provisions of this Article.
8.02. Maintenance and Reserve Funds. The Board will establish a maintenance fund and a
self-sustaining reserve fund; all moneys paid to the Association will be deposited into these
accounts, and disbursements will be made from them in performing the functions of the
Association under this Declaration. The reserve fund will be maintained and used for
unexpected and emergency costs. The maintenance fund will be maintained and used for the
day-to-day operating expenses, repairs, taxes and maintenance of all Common Area and
Facilities. The funds of the Association deposited into the maintenance and reserve funds must
be used solely for purposes authorized by this Declaration, as it may from time to time be
amended.
8.03. Regular Annual Assessments. Before the beginning of each fiscal year, the Board will
estimate the expenses to be incurred by the Association during the year in performing its
functions under the Restrictions, which will be limited to the costs incurred in exercising the
powers granted to the Association in Section 6.04, the cost of enforcing the Restrictions, and a
reasonable provision for contingencies and appropriate replacement reserves, less any expected
income and any surplus from the prior year’s fund. Assessments sufficient to pay the estimated
net expenses will then be levied as provided in this Declaration, and the level of Assessments
set by the Board will be final and binding if it is made in good faith. All regular Assessments
will be due and payable to the Association at the beginning of the fiscal year or, in any other
manner as the Board may designate in its sole and absolute discretion. First year regular
assessments will be prorated from the Closing Date based upon the house under construction
rate of 1/2 of annual assessment for the earlier date from the closing date of the lot to the
completion date of the house or nine months following the lot closing date. In no event will the
maximum regular annual Assessments per Lot be increased by more than twenty five percent
(25%) per year, unless approved by fifty-one percent (51%) of Members who are voting in
person or by proxy at a meeting duly called for that purpose, with the same quorum as required
for Special Assessments. Until and unless otherwise determined by the Declarant and/or
Board, the maximum regular assessment shall be Three Thousand dollars ($3,000) per lot
per year, to be paid in full at the due date. If any assessment remains unpaid at the
expiration of thirty (30) calendar days from and after the due date established by the Declarant
and/or the Board, a late charge maybe assessed, if permitted by applicable law, against the non-
paying Owner for each month that any portion of an assessment remains unpaid. The late
charge shall be in the amount of twenty-five dollars ($25) for all class “A” shares. A
reasonable service charge in an amount established by the Board may be charged for each
check that is returned because of insufficient funds.
8.04. Special Assessments. In addition to the regular annual Assessments provided for above,
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 22 of 32
the Board may levy special Assessments to enable the Board to car ry out the mandatory
functions of the Association under the Restrictions on the approval of at least fifty-one percent
(51%) of the Members at a meeting called for that purpose, by adequate notice, with at least
fifty percent (50%) of the Members or their proxies present at the meeting to be a quorum. If
fifty percent (50%) of the Members do not attend, a second meeting may be called with the
same notice and the quorum needed for the second meeting will be thirty percent (30%) of the
Members or their proxies.
8.05. Owner’s Personal Obligation for Payment of Assessments. The regular Assessments
provided for in this Declaration will be the personal and individual debt of the Owner of the
Lot covered by the Assessments. Each Owner of a Lot by acceptance of a deed, whether or not
it shall be so expressed in such deed, is deemed as a part of the purchase money consideration
of for such deed and conveyance to covenant and agree to pay to the Declarant and/or the
Association, or to an independent entity or agency which may be designated by the Declarant
and/or the Association to receive such monies. No Owner may exempt itself from liability for
the Assessments. For any default in the payment of any Assessment, the Owner of the Lot will
be obligated to pay an annual interest rate of ten percent (10%) on the amount of the
Assessment from the Assessment's due date, together with all costs and expenses of collecti on,
including reasonable attorney fees.
8.06. Assessment Lien and Foreclosure. All amounts assessed in the manner provided in this
Article but unpaid will, together with interest as provided in Section 8.05 and the cost of
collection, including attorney fees as provided in this Declaration, become a continuing lien
and charge on the Lot covered by the Assessment that will bind the Lot in the hands of the
Owner and the Owner’s heirs, devisees, personal representatives, successors, or assigns. This
lien will be superior to all other liens and charges against the Lot, except for tax liens and all
amounts unpaid on a Mortgage lien of record of first or second priority granted to an
institutional lender, securing in either instance amounts borrowed for the purchase or
improvement of the Lot in question. The Association will have the power to subordinate the
Assessment lien to any other lien. This power will be entirely discretionary with the Board and
the subordination must be signed by a duly authorized officer of the Association. To evidence
the Assessment lien, the Association may prepare a written notice of Assessmen t lien setting
forth the amount of the unpaid indebtedness, the name of the Owner of the Lot covered by the
lien and a description of the Lot. This notice will be signed by one of the officers of the
Association and will be recorded in the office of the County Clerk of Tarrant County, Texas.
The lien for payment of Assessments will attach with the priority above set forth from the date
that the payment becomes delinquent. The Association may direct its legal counsel to initiate
legal proceedings in a court of competent jurisdiction seeking one or both of the following
remedies:
(a) Foreclosure of the assessment lien under the rules adopted by the Texas Supreme
Court for expedited foreclosure proceedings. The Association’s assessment lien may not be
foreclosed, however, until the Association has (i) provided written notice of the total amount
of the delinquency giving rise to the foreclosure to all lienholders of record (evidenced by a
deed of trust) whose liens are inferior or subordinate to the Associatio n’s assessment lien,
and (ii) provided each such lienholder an opportunity to cure the delinquency before the
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 23 of 32
sixty-first (61st) day after the date the lienholder receives the notice. The notice to
lienholders must be sent by certified mail, return receipt requested, to the address for the
lienholder shown in the deed of trust burdening the Lot(s) subject to the Association’s
assessment lien.
(b) Recovery of a personal judgment against the Current Owner and, where different,
from the Delinquent Owner or from the Current Owner only, for all amounts owing arising
from the unpaid Assessments and their collection, including all attorney fees and costs.
(c) The Association will have the power to bid on the property at a foreclosure or
other legal sale and to acquire, hold, lease, mortgage, convey, or otherwise deal with it. On
the written request of any Mortgagee, the Association will report to the M ortgagee any
unpaid Assessments remaining unpaid for longer than thirty (30) days after they are due.
(d) The amount of the assessments assessed against the Lot shall also be a personal
obligation or indebtedness of the Owner thereof at the time the assessment is made. Suit to
recover a money judgment for unpaid assessments shall be maintainable without foreclosing
or waiving the lien securing the same.
(e) Owner, by acceptance of the deed to the Property, hereby expressly vests in
Declarant, the Board or its agents the right and power to bring all actions against Owner
personally for the collection of such charges as a debt, and to enforce the aforesaid lines by
all methods available for the enforcement of such liens. No Owner may waive or otherwise
escape liability for the assessments provided herein by non-use of the Common Properties or
by abandonment of his Lot.
ARTICLE 9
EASEMENTS
9.01. Reserved Easements. All dedications, limitations, restrictions, and reservations shown
on the Plat and all grants and dedications of easements, rights-of-way, restrictions, and related
rights made before the Property became subject to this Declaration are incorporated by
reference and made a part of this Declaration for all purposes as if fully set forth in this
Declaration and will be construed as being adopted in each and every contract, deed, or
conveyance executed or to be executed by or on behalf of Declarant conveying any part of the
Property. Declarant reserves the right to make changes in and additions to the easements for
the purpose of most efficiently and economically developing the Property. Further, Declarant
reserves the right, without the necessity of the joinder of any Owner or other Person, to grant,
dedicate, reserve, or otherwise create, at any time or from time to time, easements for public-
utility purposes (including without limitation gas, water, electricity, telephone, and drainage) in
favor of any Person along any front, rear, or side boundary line of any Lot, which easements
will have a maximum width of fifteen (15) feet.
9.02. Installation and Maintenance. There is by this Declaration created, for the benefit of
the City and other governmental entities and public utilities with jurisdiction over or providing
utility services to the Subdivision, an easement on, across, over, and under all of the Property
for ingress and egress in connection with installing, replacing, repairing, and maintaining all
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 24 of 32
utilities (including but not limited to water, wastewater, gas, telephones, electricity lines, and
related appurtenances) and for conducting authorized official governmental business. By virtue
of this easement, it will be expressly permissible for the utility companies and other entities
supplying utility service to install and maintain pipes, wires, conduits, service line, or other
utility facilities or appurtenances on, above, across, and under the Property, within the public-
utility easements from time to time existing and from service lines situated within the
easements to the point of service on or in any Improvement. Despite any provision contained in
this Section, no electrical lines, water lines, or other utilities or appurtenances may be relocated
on the Property until approved by Declarant or the Architectural Committee. The utility
companies furnishing services to the Subdivision and governmental entities conducting
authorized official governmental business within the Property will have the right to remove all
trees and other obstructions situated within the utility easements shown on the Plat that are
obstructing or otherwise precluding accomplishment of the authorized official governmental
business, and to trim overhanging trees and shrubs located on portions of t he Property abutting
the easements. If the City is required to remove any trees or other obstructions in order to
accomplish any authorized governmental business within the Property, then the City may
assess the reasonable costs and expenses required for the removal to the Association, and the
Association will be reimbursed, on written demand, for all costs and expenses from the Owner
of the Lot(s) on which the obstructions were located. Any reimbursement required to be paid
by any Owner under this Declaration will be deemed a regular Assessment of the Owner and
will be paid in accordance with, and secured by the lien described in, Article 8.
9.03. Drainage Easements. Each Owner covenants to provide easements for drainage and
water flow, as contours of land and the arrangement of Improvements approved by the
Architectural Committee require. Each Owner further covenants not to disturb or displace any
trees or other vegetation within the drainage easements as defined in this Declaration and
shown on the Plat. There will be no construction of Improvements, temporary or permanent, in
any drainage easement, except as approved in writing by the Architectural Committee.
9.04. Surface Areas. The surface of easement areas for underground utility services may be
used for planting of shrubbery, trees, lawns, or flowers. However, neither the Declarant nor any
supplier of any utility service using any easement area will be liable to any Owner or to the
Association for any damage done by them or either of them, or their respective agents,
employees, servants, or assigns, to any of this vegetation as a result of any activity relating to
the construction, maintenance, operation, or repair of any facility in any of these easement
areas.
9.05. Common Area and Facilities. Each Owner will have a nonexclusive easement for use
and enjoyment in and to all Common Area and Facilities, which will be appurtenant to and will
pass with title to each Owner’s Lot, subject to the following rights:
(a) The right of the Association to suspend the Owner’s right to use the Common Area
and Facilities for any period during which an Assessment against the Owner’s Lot remains
unpaid, and for any period during which the Owner is in violation of the rules and regulations
of the Association.
(b) The right of the Association to borrow money for the purpose of improving the
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 25 of 32
Common Area and Facilities and, in furtherance of this purpose, to mortgage the Common
Area and Facilities, all in accordance with the Certificate of Formation and Bylaws.
(c) The right of Declarant or the Association, as applicable, to promulgate reasonable
rules and regulations regarding use of the Common Area and Facilities.
(d) The right of Declarant or the Association, as applicable, to contract for services
with third parties on any terms as Declarant or the Association may determine.
9.06. Self-Help Easement. Each Owner grants to the Association an easement on, over, and
across its Lot for purposes of curing any violation of the restrictions, covenants, and
obligations set forth in this Declaration.
ARTICLE 10
MISCELLANEOUS PROVISIONS
10.01. Term. This Declaration, including all of its covenants, conditions, and restrictions, will
be effective on the date this Declaration is recorded in the Real Property/Official/Deed Records
of Tarrant County, Texas, and will continue in effect for a period of thirty (30) years, after
which it will be automatically extended for two (2) successive periods of ten (10) years each,
unless amended or extinguished as set forth in Section 10.02.
10.02. Amendment; Extinguishment. This Declaration may be amended or extinguished in
whole or in part, only with the consent of Declarant and fifty one percent (51%) of all Owners.
All provisions of this Declaration may be amended or extinguished by the recording in the Real
Property/Official/Deed Records of Tarrant County, Texas of an instrument executed and
acknowledged by the President and Secretary of the Association, setting forth the amendment
or extinguishment and certifying that the amendment or extinguishment has been approved by
Owners entitled to cast at least fifty-one percent (51%) of the number of votes entitled to be
cast under Section 6.03.
10.03. Notices. Any notice permitted or required to be given by this Declaration will be in
writing and may be delivered either by certified mail, return receipt requested, or by personal
delivery with a written receipt received. If delivery is made by certified mail, it will be deemed
to have been delivered the date on which it was received by the Person to whom the notice was
addressed. The address at which a Person is given notice may be changed from time to time by
notice in writing given by the Person to the Association.
10.04. Governing Law. The provisions of this Declaration will be liberally construed to
effectuate the purposes of creating a uniform plan for the development and operation of the
Property and of promoting and effectuating the fundamental concepts of the Property set forth
in this Declaration. This Declaration will be governed by and interpreted under the laws of the
State of Texas.
10.05. Exemption of Declarant. Despite any provision in this Declaration to the contrary,
neither Declarant nor any of Declarant’s activities will in any way be subject to the control of
or under the jurisdiction of the Architectural Committee or the Board. Without in any way
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 26 of 32
limiting the generality of the preceding sentence, this Declaration will not prevent or limit the
right of Declarant to excavate and grade, to construct and alter drainage patterns and facilities,
to construct any and all other types of improvements, sales and leasing offices, and similar
facilities, and to post signs incidental to construction, sales, and leasing anywhere within the
Property.
10.06. Non-liability of Architectural Committee and Board Members. The Architectural
Committee, the Board, and their members will not be liable to the Association or to any Owner
or to any other Person for any loss, damage, or injury arising from their being in any way
connected with the performance of the Architectural Committee’s or the Board’s duties under
this Declaration unless due to the willful misconduct or bad faith of the Architectural
Committee, the Board, or their members, as the case may be.
10.07. Assignment of Declarant. Despite any provision in this Declaration to the contrary,
Declarant may assign, in whole or in part, any of its privileges, exemptions, rights, and duties
under this Declaration to any other Person and may permit the participation, in whole or in
part, by any other Person in any of these privileges, exemptions, rights, and duties.
10.08. Enforcement and Non-waiver. Except as otherwise provided in this Declaration, any
Owner at its own expense, Declarant, the Association, and the Board will have the right to
enforce any and all provisions of the Restrictions. This right of enforcement will include both
damages for, and injunctive relief against, the breach of any provision. The failure to enforce
any provision at any time will not constitute a waiver of the right to enforce the provision or
any other provision in the future. Also, the violation of any of the Restrictions by an Owner or
the Owner’s family, guests, tenants, lessees, or licensees will authorize the Board, acting on
behalf of the Association, to avail itself of any one or more of the following remedies in
addition to any other available remedies:
(a) The imposition of a special charge not to exceed One Thousand Dollars ($1,000)
per violation.
(b) The suspension of the Owner’s rights to use any Common Area and Facilities or
other Association property so long as a violation exists.
(c) The right to cure or abate the violation and to charge any related expenses to the
Owner.
(d) The right to seek injunctive and any other relief provided or allowed by law
against the violation and to recover from the Owner all of the Association’s related expenses
and costs, including but not limited to attorney fees and court costs. Before the Board may
invoke the remedies provided above, it must give notice of the alleged violation to the Owner
in the manner specified in Section 10.03, and must give the Owner an opportunity to request
a hearing. If, after the hearing, or if no hearing is requested, after the deadline for requesting
a hearing has passed, the Board determines that a violation exists, the Board’s right to
proceed with the listed remedies will become absolute. Each day a violation continues will be
deemed a separate violation. All unpaid special charges imposed under this Section for
violation of the Restrictions will be the personal obligation of the Owner of the Lot for which
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 27 of 32
the special charge was imposed and will become a lien against the Lot and all Improvements
on it. The liens will be prior to any declaration of homestead and the Association may
enforce payment of the special charges in the same manner as provided in Article 8. Despite
any provision in this Section to the contrary, the Board will not be required to afford an
Owner a hearing before the filing of a lawsuit to collect past-due Assessments.
10.09. Severability. The provisions of the Restrictions will be deemed independent and
severable, and the invalidity or partial invalidity of any provision or portion of a provision will
not affect the validity or enforceability of any other provision or portion of a provision. Unless
the context requires a contrary construction, the singular includes the plural and the plural the
singular, and the masculine, feminine, or neuter each includes the masculine, feminine, and
neuter. All headings and titles used in this Declaration are intended solely for convenience of
reference and will not enlarge, limit, or otherwise affect that which is set forth in any of the
paragraphs, sections, or articles in this Declaration.
10.10. Disputes. The Declarant and/or the Board shall determine matters of dispute or
disagreement between Owners with respect to interpretation or application of the provisions of
this declaration except for where decision-making authority has been granted to the
Architectural Review Committee. These respective determinations, absent arbitrary and
capricious conduct or gross negligence, shall be final and binding upon all Owners.
10.11. Security. Declarant and the Association may, but shall not be obligated to maintain or
support certain activities within the development to make the development more secure then it
already might be. Neither the Association, the Declarant, nor any successor Declarant shall in
any way be considered an insurer or guarantor of security within the development, nor shall the
association or the declarant be held liable for any loss or damage by reason of failure to
provide adequate security or of ineffectiveness of security measures taken. No representation
or warrant y is made that any fire protection system, burglar alarm s ystem or other security
system cannot be compromised or circumvented, nor that any such systems or security
measures undertaken will in all cases prevent loss or provide the detection or protection for
which the system is designed or intended. Each owner acknowledges, understands and
covenants to inform its tenants that the Association, its Board, Architectural Committee and
Declarant and any successor Declarant, are not insurers and that each person using the property
within the development assumes all risks for loss or damage to person, to lots, to personal
property and to the contents of residences on lots resulting form the acts of third parties.
10.12. Power of Attorney. Each and every Owner hereby makes, constitutes and appoints
Declarant as his/her true and lawful attorney-in-fact, coupled with an interest and irrevocable,
for him/her and in his/her name, place and stead and for his/her use and benefit, to do the
following:
(a) to exercise, do or perform any act, right, power, duty or obligation whatsoever in
connection with, arising out of, or relating to any matter whatsoever involving this
Declaration, or any part hereof, with such clauses, recitals, covenants, agreements and
restrictions as Declarant shall deem necessary, proper and expedient under the conditions as
may then be existing.
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 28 of 32
(b) to sign, execute, acknowledge, deliver and record any and all instruments which
modify, amend, change, enlarge, contract or abandon the terms within this Declaration, or
any part hereof, with such clauses, recitals, covenants, agreements and restrictions as
Declarant shall deem necessary, proper and expedient under the circumstances and
conditions as may be then existing.
(c) to sign, execute, acknowledge, deliver and record any and all instruments which
modify, amend, change, enlarge, contract or abandon the subdivision plat of the Property, or
any part thereof, with any easements and right-of-way to be therein contained as the
Declarant shall deem necessary, proper and expedient under the conditions as may then be
existing.
(d) any proposed changes to the terms or conditions of the Declaration that effects or
changes the obligations, rights, or duties of any Owner who was an Owner at the time of the
execution of this Declaration can only be proposed by the D eclarant and not the individual
lot Owners and requires consent and approval of more than 51% (fifty-one percent) of such
effected Owners.
(e) The rights, powers and authority of said attorney-in-fact to exercise any and all of the
rights and powers herein granted shall commence and be in full force upon recordation of
this Declaration in the Tarrant County Clerk’s Office and shall remain in full force and effect
thereafter until the third anniversary of the initial Lot sale closing and Declarant owns no
more than one (1) Lot, or upon the date after said third anniversary Declarant becomes the
Owner of a single Lot, Declarant will immediately transfer management of the Association to
the Owners and will relinquish Declarant’s disproportionate number of votes. Upon this
event, Declarant will become a Class A Member and will be subject to the same financial
obligations as the other Class A Members within. Additionally, Declarant agrees that after
the occupancy of [INSERT NUMBER] homes within Maranatha Residential, Declarant, as
manager of the Association, will not call for a Special Assessment of the Association without
approval of a majority of the occupying Owners.
(The remainder of this document is intentionally blank; execution to follow.)
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 29 of 32
EXECUTED as of ________________________, 20___.
DECLARANT:
SRI Southlake Villas, LLC,
a Texas Limited Liability Company
By: _______________________
Name:
Title: Managing Member
STATE OF TEXAS §
§
COUNTY OF TARRANT §
BEFORE ME, the undersigned, a Notary Public in and for the State of Texas, on this day
personally appeared [NAME] of SRI Southlake Villas, LLC, known to me to be the person and
officer whose name is subscribed to the foregoing instrument and acknowledged to me that it
was the act of SRI Southlake Villas, LLC, a Texas Limited Liability Corporation, and that he
executed it as the act of the corporation for the purposes and consideration expressed in it, and
in the capacity stated in it.
GIVEN UNDER MY HAND AND SEAL OF OFFICE, this ____ day of _______, 20____.
___________________________
Notary Public – State of Texas
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 30 of 32
Exhibit A
Legal Description
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 31 of 32
Exhibit “B”
Fence Specifications
_____________________________________________________________________________________________________________________
CC&Rs for Maranatha Residential, Southlake, TX dated May **, 2019 Page 32 of 32
Exhibit “C”
Mailbox Specifications